Manual Pad Government Bids & RFPs

Bids must be received by 2:00 p. m. on Thursday, November 19, 2026. Bids must be received by the date and time specified. Late bids will be rejected and returned unopened to the bidder.

The contract will be awarded to the lowest bidder. Lowest bidder will be determined by the lowest total bid amount.

Contractor must have a Class A license and be registered with DIR. This project requires the contractor to have a class a license. and bidders/contractors and all subcontractors must be registered with the state of california department of industrial relations

Liquidated damages of $9,500 per day for delay. the contractor shall pay the city of visalia the sum of nine thousand and five hundred dollars 9,**** per day for each and every calendar day of delay

Mandatory prebid meetings are scheduled at the jobsite. mandatory prebid meetings have been scheduled for this project. bidder prime contractor attendance at one 1 of the prebid meetings is required

Questions must be received by Wednesday, October 28, 2026. questions must be received by wednesday, october 28, 2026.

Failure to submit required qualifications with bid may result in nonresponsive bid. failure to submit the required qualifications with the bid may result in the bid being deemed nonresponsive.

The engineer's estimate is $28,000,000. the probable construction cost is estimated to be: 28,000,000.

Bids must be received by October 22, 2026 at 2:30 PM. received up to and including thursday, october 22, 2026 at 2: 30 p. m. , prevailing time.

Payment after acceptance of merchandise with detailed invoice. payment shall be made after county acceptance of merchandise, with the submission of a detailed invoice. Typically 60 days for non-construction contracts.

Award to lowest priced bids. awards may be made to the responsive and responsible bidders submitting the lowest priced bids.

Bidders must be registered to do business in New York. bidders must be properly registered to do business in the state of new york and furnish applicable certificates of authority.

Samples may be requested for substituted products. samples may be requested by the county in order to verify compliance with the specifications.

Questions must be submitted by October 7, 2026. all questions must be submitted by wednesday, october 7, 2026 at 3: 00 p. m. .

Bids may be rejected if nonresponsive. any bid form which contains modifications. . . is illegible conditional or unsigned may be rejected as nonresponsive.

Bids must be received by November 4, 2026, 2:00 PM. The document states: all bids shall be received on or before the above designated date and time.

The bid includes a warranty requirement: warranty 2 years or suggested warranty above 2 years as part of the specifications.

Awards will be made to the best responsible bidder. The document states: awards will be made to the best responsible bidder as determined by the city of ringgold.

Contractor must comply with E-Verify. The document states: the undersigned contractor verifies its compliance with ****, stating affirmatively that the individual, firm or corporation. . . has registered with. . . everify.

Bids not properly labeled will be returned unopened. The document states: any deviation from the requirements set forth for the labeling of the bid envelopes shall result in said bid being returned to the bidder unopened.

Project shall be completed within 240 calendar days after issuance of a notice to proceed. project shall be completed within 240 calendar days after issuance of a notice to proceed.

All bidders must be properly licensed under state laws governing their trades. all bidders are hereby notified that they must be properly licensed under the state laws governing their prospective trades.

A mandatory prebid conference and site visit will be held at 10:00 AM on October 8, 2026. a mandatory prebid conference will be held at 10: 00 am local time on october 8, 2026

Questions must be received by 5:00 PM on October 15, 2026. questions must be received by 5: 00pm on october 15, 2026.

Bids will not be accepted from bidders who do not attend the mandatory prebid conference. bids will not be accepted from bidders who do not attend the mandatory prebid conference.

The contract will be awarded to the lowest responsible bidder. As stated: award to contract will be made only to the lowest responsible bidder, whose proposal shall comply with all the provisions required to make it normal.

Bidders must have a certified pool operator on staff. As stated: respondents shall have a certified pool operator as part of thier staff plan.

Bids may be deemed incomplete if bid deposit is not submitted. As stated: if the bid deposit is not submitted with the bid, the bid may be deemed incomplete and will not be considered.