This tender notice is for truck drivers, specifically for various types of trucks including concrete mixers, transit mixers, dry batch trucks, distributor trucks, dump trucks, flatbed trucks, and more. The notice details the responsibilities and requirements for truck drivers, including classifications and pay provisions. It also includes extensive general conditions of the contract for construction, covering definitions, contract documents, owner and contractor responsibilities, changes in work, time, payments, insurance, bonds, and termination clauses. The State of Montana Fish, Wildlife and Parks is the issuing agency.
The bid notice states that all work shall reach substantial completion within: sixty 60 consecutive calendar days. The owner will issue a written notice to proceed and finalized contract. all work shall reach substantial completion within: sixty 60 consecutive calendar days. The owner will issue a written notice to proceed and finalized contract.
The bid notice states that until the work is complete, the owner will pay 95 of the amount due the contractor on account of progress payments. Until the work is complete, the owner will pay 95 of the amount due the contractor on account of progress payments.
The bid notice states that the contractor warrants to the owner and architectengineer that materials and equipment furnished under the contract will be new and of good quality unless otherwise required or permitted by the contract documents, that the work will be free from defects not inherent in the quality required or permitted, and that the work will conform to the requirements of the contract documents. The contractor warrants to the owner and architectengineer that materials and equipment furnished under the contract will be new and of good quality unless otherwise required or permitted by the contract documents, that the work will be free from defects not inherent in the quality required or permitted, and that the work will conform to the requirements of the contract documents.
The bid notice states that the owners engagement of the contractor is based upon the contractors representations by submission of a bid to the owner that it has the requisite skills, judgment, capacity, expertise, and financial ability to perform the work, is experienced in the type of labor and services the owner is engaging the contractor to perform, is authorized, licensed and registered to perform the type of labor and services for which it is being engaged in the state and locality in which the project is located, is qualified, willing and able to perform the labor and services for the project in the manner and scope defined in the contract documents and, has the expertise and ability to provide labor and services that will meet the owners objectives, intent and requirements, and will comply with the requirements of all governmental, public, and quasipublic authorities and agencies having or asserting jurisdiction over the project. The owners engagement of the contractor is based upon the contractors representations by submission of a bid to the owner that it: 3. 1. 3. 1. has the requisite skills, judgment, capacity, expertise, and financial ability to perform the work **** experienced in the type of labor and services the owner is engaging the contractor to perform **** authorized, licensed and registered to perform the type of labor and services for which it is being engaged in the state and locality in which the project is located **** qualified, willing and able to perform the labor and services for the project in the manner and scope defined in the contract documents and, 3. 1. 3. 5. has the expertise and ability to provide labor and services that will meet the owners objectives, intent and requirements, and will comply with the requirements of all governmental, public, and quasipublic authorities and agencies having or asserting jurisdiction over the project.
The bid notice states that the owner may suffer loss if the project is not substantially complete on the date set forth in the contract documents. The contractor and his surety shall be liable for and shall pay to the owner the sums hereinafter stipulated as liquidated damages for each calendar day of delay until the work is substantially complete: fifty and **** dollars ****. The contractor and his surety shall be liable for and shall pay to the owner the sums hereinafter stipulated as liquidated damages for each calendar day of delay until the work is substantially complete: fifty and **** dollars ****.
The bid notice states that execution of the contract by the contractor is a representation that the contractor has visited the site, become generally familiar with local conditions under which the work is to be performed, and correlated personal observations with requirements of the contract documents. Execution of the contract by the contractor is a representation that the contractor has visited the site, become generally familiar with local conditions under which the work is to be performed, and correlated personal observations with requirements of the contract documents.
The bid notice defines samples as physical examples which illustrate materials, equipment or workmanship and establish standards by which the work will be judged. Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the work will be judged.
