USA
Dept Of Defense- Dept Of The Air Force- Pacific Air Forces- Fa5205 35 Cons Pk
Roads/Pavements & Misc. Civil Work Indefinite- Delivery/Indefinite- Quantity ( IDIQ) Contract, Misawa Air Base, Japan - The scope of the contract encompasses repair, maintenance and construction of pavement structures such as roads and parking lots, and related work including but not limited to curb/gutter, drainage pipes, manhole, earthwork, sidewalks, markings, t
Roads Pavements Misc. Civil Work IDIQ Contract
AI helper
The contractor shall complete the entire work ready for use not later than 365 calendar days after receiving award, notice to proceed. The bid notice states complete it within 365 calendar days after receiving award, notice to proceed.
The bid notice states that payments will be made by the contracting officer and that progress payments will be made monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished. The bid notice states Payment will be made by contracting officer will complete item 28 or 29 as applicable and The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.
The bid notice states that the contractor warrants that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the contractor or any subcontractor or supplier at any tier. This warranty shall continue for a period of 1 year from the date of final acceptance of the work. The bid notice states he contractor warrants, except as provided in paragraph i of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the contractor or any subcontractor or supplier at any tier. and This warranty shall continue for a period of 1 year from the date of final acceptance of the work.
The bid notice indicates a subjective tradeoff best value source selection process where past performance is evaluated on a basis approximately equal to price. The bid notice states his is a competitive subjective tradeoff sto best value source selection conducted in accordance with federal acquisition regulation far part 15 in which competing offerors past performance information will be evaluated on a basis approximately equal to price.
The bid notice states that the offeror has been duly authorized to operate and to do business in the host nation country where the contract is to be performed, and must comply with any host government and political subdivisions laws, codes, and regulations applicable. The bid notice states The offeror has been duly authorized to operate and to do business in the host nation country where the contract is to be performed, and far **** modified iaw daffars **** The contractor shall be responsible for obtaining any necessary licenses and permits, and for complying with any host government and political subdivisions laws, codes, and regulations applicable.
The bid notice states that if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of JPY 80,871 for the first calendar day of delay and JPY 37,779 for each calendar day of delay until the work is completed or accepted. The bid notice states If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of JPY 80,871 for the first calendar day of delay and JPY 37,779 for each calendar day of delay until the work is completed or accepted.
A job site visit will be held on February 18, 2026, at **** hours in the 35th Contracting Squadron conference room. The bid notice states Job site visit will be held on 18 Feb 26 at **** hours in the 35th Contracting Squadron conference room.
The estimated ordering amount per year under the resulting contract is between 1,000,000 and 5,000,000 or equivalent yen amount. The bid notice states The estimated ordering amount per year under resulting contract is between 1, 000, 000 and 5, 000, 000 or equivalent yen amount, see sec. l100, para. b. 3 c5 for fy2026 fcfd budget rate.
Bid Close Date:
