Weld County School District 6 seeks proposals to supply and install specialized security glass (SG4TM IGUS) and/or retrofit security laminate systems (Safe Haven Defense) at Prairie Heights Middle School. Key requirements include manufacturer certifications, installer qualifications (no unauthorized subcontracting for laminate), and an operational minimization plan for zero disruption. A mandatory prebid meeting is scheduled for September 16, 2026. Bids must be emailed by September 30, 2026. The contract guarantees for materials and workmanship are for one year from final acceptance.
Payments will be based on ninety percent 90 of total value of work completed and material in place as mutually agreed upon, less all previous payments. payments will be based on ninety percent 90 of total value of work completed and material in place as mutually agreed upon, less allprevious payments.
The contractor shall guarantee all materials, workmanship and the satisfactory operation of all equipment installed and/or finished, for a period of one 1 year from the date of the final acceptance of the entire work. the contractor shall guarantee all materials, workmanship and the satisfactory operation of all equipment installed andor finished, for a period of one 1 year from the date of the final acceptance of the entire work
Awards will be made to the lowest qualified, responsible bidder. awards will be made to the lowest qualified, responsible bidder.
Proposals must include manufacturer certifications and a statement confirming that all field personnel are direct, corporate trained employees. proposals must include the following distinct sections to be considered: o manufacturer certifications: documented proof that the bidding contractor is a certifiedauthorized installer of school guard glass andor safe haven defense systems.
If work is not completed by the specified date, liquidated damages of $1,**** for each calendar day will be deducted. if, in the districts judgment work is not completed by the specified completion date there shall be deducted from the amount due the contractor, as liquidated damages accruing to the district, the sum of 1, **** for each calendar day, per project, beyond the specified completion date until work is completed.
Each bidder shall carefully examine the drawings, read the specifications and all other contract documents, and visit the site of the work. each bidder shall carefully examine the drawings, read the specifications and all other contract documents, and visit the site of the work.
The district reserves the right to reject any bid from any contractor deemed unqualified by the district. the district reserves the right to reject any bid from any contractor deemed unqualified by the district.
