AI helper
The project involves the construction of levee enlargements and berms in Tensas Parish, Louisiana. The work includes furnishing all plant, labor, materials, and equipment for seepage berms, stability berm, and levee enlargement. The estimated price range is above $10,000,000. The contractor must begin work within 10 calendar days and complete it within 320 calendar days after receiving the notice to proceed. The opening date for offers is December 9, 2025. The lowest responsive, responsible bidder will be awarded the contract. A site visit is recommended. The contractor must have a site safety and health officer ssho at the work site at all times to perform safety and occupational health management, surveillance, inspections, and safety enforcement for the contractor. The contractor must provide a cqc plan, prior to start of construction that includes a table of contents, with major sections identified, pages numbered sequentially, and that documents the proposed methods and responsibilities for accomplishing quality control during the construction of the project. The contractor must maintain a list of work that does not comply with the contract, identifying what items need to be corrected, the activity id number associated with the item, the date the item was originally discovered, the date the item will be corrected by, and the date the item was corrected. The contractor must maintain current and complete records of onsite and offsite qc program operations and activities. The contractor must use the governmentfurnished construction contractor mode of rms, referred to as rms cm, to record, maintain, and submit various information throughout the contract period. The contractor must provide a site safety and health officer ssho at the work site at all times to perform safety and occupational health management, surveillance, inspections, and safety enforcement for the contractor. The contractor must provide a cqc plan, prior to start of construction that includes a table of contents, with major sections identified, pages numbered sequentially, and that documents the proposed methods and responsibilities for accomplishing quality control during the construction of the project. The contractor must maintain a list of work that does not comply with the contract, identifying what items need to be corrected, the activity id number associated with the item, the date the item was originally discovered, the date the item will be corrected by, and the date the item was corrected. The contractor must maintain current and complete records of onsite and offsite qc program operations and activities. The contractor must use the governmentfurnished construction contractor mode of rms, referred to as rms cm, to record, maintain, and submit various information throughout the contract period. The contractor must provide a site safety and health officer ssho at the work site at all times to perform safety and occupational health management, surveillance, inspections, and safety enforcement for the contractor. The contractor must provide a cqc plan, prior to start of construction that includes a table of contents, with major sections identified, pages numbered sequentially, and that documents the proposed methods and responsibilities for accomplishing quality control during the construction of the project. The contractor must maintain a list of work that does not comply with the contract, identifying what items need to be corrected, the activity id number associated with the item, the date the item was originally discovered, the date the item will be corrected by, and the date the item was corrected. The contractor must maintain current and complete records of onsite and offsite qc program operations and activities. The contractor must use the governmentfurnished construction contractor mode of rms, referred to as rms cm, to record, maintain, and submit various information throughout the contract period.
The contractor shall begin performance within 10 calendar days and complete it within 320 calendar days after receiving award, notice to proceed. The contractor shall begin performance within 10 calendar days and complete it within 320 calendar days after receiving award, notice to proceed.
Award will be made, as a whole to the lowest responsive, responsible bidder as may be in the best interest of the government. h award will be made, as a whole to the lowest responsive, responsible bidder as may be in the best interest of the government.
Lack of registration in the www. ***. *. * database will make an offeror ineligible for award. k lack of registration in the www. ***. *. * database will make an offeror ineligible for award.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 1, **** for each calendar day of delay until the work is completed or accepted. a if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 1, ****contracting officer insert amount for each calendar day of delay until the work is completed or accepted.
Offerors or bidders should visit the site and take such other steps as may be reasonably necessary to ascertain the nature and location of the work, and the general and local conditions which can affect the work or the cost thereof. 5. conditions affecting the work. offerors or bidders should visit the site and take such other steps as may be reasonably necessary to ascertain the nature and location of the work, and the general and local conditions which can affect the work or the cost thereof.
The estimated price range of this project is above 10, 000, 000. in accordance with far **** disclosure of the magnitude of construction projects, the estimated price range of this project is above 10, 000, 000.
