This is a public tender notice for the Rehab Rainy and Ash Pavement Preservation Project at Voyageurs National Park in Minnesota. The contract involves construction, alteration, or repair of highways, roads, streets, bridges, and railways. It is a small business set-aside procurement. The contractor shall begin performance within 10 calendar days and complete it within 195 calendar days after receiving award, notice to proceed. Offers are due by **** local time on 06/09/2026 and will be publicly opened at that time. The delivery location for offers is Denver, CO. The North American Industrial Classification System (NAICS) code is ****.
The contractor shall complete the entire work ready for use not later than 195 calendar days after receiving award, notice to proceed. The time stated for completion shall include final cleanup of the premises.
Payment will be made by DOI, NPS, DSC Contracting Services. Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform (IPP) system.
The government will conduct a source selection using the best value continuum tradeoff process. The contracting officer will award a contract to the offeror who submits a proposal that conforms to solicitation requirements, is fair and reasonable, and provides the best value to the government considering all evaluation factors combined.
The offeror must be registered in www. ***. *. * at the time an offer is submitted. The technical evaluation will consider project experience and key personnel, past performance, and project schedule. The business and price proposal will be reviewed for completeness and eligibility.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of $1,**** for each calendar day of delay until the work is completed or accepted.
A site visit will be announced via amendment. Participants will meet at Voyageurs National Park Headquarters.
Protests must be served on the contracting officer by obtaining written and dated acknowledgment of receipt from ***@***. *. * within one day of filing a protest with the GAO.