Infrastructure Government Bids & RFPs

The contractor shall complete all work not later than 120 calendar days after receiving the contract award, from the start date in the notice to proceed. his performance period is mandatory, negotiable.

Requests for payment may be made no more frequently than monthly, covering the value of labor and materials completed and in place. after receipt of the contractors request for payment, and on the basis of an inspection of the work, the contracting officer shall make a determination as to the amount, which is then due.

The project guarantee is for one 1 year (365 days) after issue of certificate of final inspection and acceptance. he contractor shall provide with oneyear warranty of the works and products.

Offerors must be technically qualified and financially responsible, able to understand English, have an established business, and possess necessary personnel, equipment, and financial resources. offerors must be technically qualified and financially responsible to perform the work described in this solicitation.

The contract includes a clause for liquidated damages for construction, but specific details are **** liquidated damages construction sep **** reserved.

The contractor shall submit product data and color samples prior to work for approval by the COR. he contractor shall submit product data and color samples prior to work for approval by the cor.

Failure to comply with safety requirements or discovery in an unauthorized area can lead to stop work orders or contract termination. if the contractor fails or refuses to promptly take corrective action, the u. s. g. contracting officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken.

The entire work must be completed and ready for use no later than twenty-five (25) calendar days after the date the contractor receives the notice to proceed.

Requests for payment may be made no more frequently than monthly. Payment requests shall cover the value of labor and materials completed and in place. The 14-day period for payment is changed to 30 days. Invoices shall be submitted electronically in PDF format to ***@***. *. * and one copy to the COR.

The contractor shall guarantee the workmanship of the work executed for a minimum of one year from the date of formal acceptance. Manufacturer's warranty conditions shall apply for equipment and spare parts.

Award will be made to the lowest priced, acceptable, responsible quoter.

Offerors must be technically qualified and financially responsible, understand English and Italian, have an established business in Italy, provide proof of SAM registration, demonstrate prior construction experience with references, have necessary personnel and resources, possess all required licenses and permits, be able to obtain performance security, have no adverse criminal record, and no political or business affiliation contrary to US interests.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages to the government in the amount of **** for each calendar day of delay.

A site visit and pre-quotation conference have been scheduled for June 09, 2026, at 09:30. Participants will meet at Rua Sacramento & Agrave; Lapa, No. 18 Lisboa. Prior notification is required for attendance, and no electronic devices will be permitted in the embassy compound.

After the pre-quotation conference, offerors may submit written questions until 10 days before the submission of offers cutoff date.

Failure to comply with requirements, such as providing required information for security checks, may be considered grounds for rejection and/or resubmittal. Engaging in forms of trafficking, procuring commercial sex acts, or using forced labor can lead to termination for default and debarment.

The anticipated range in price of this contract will be between €60,**** and €95,****.