Guadalupe County seeks competitive sealed bids for the Stagecoach Road Overlay Project, Phase 2, which involves asphalt overlay of roadway. Bids are due on September 16, 2026, at 2:00 pm CST. Questions must be submitted in writing via email by September 2, 2026. The contract period is for one year. Liquidated damages are set at **** per calendar day for delay in substantial completion. Bidders must meet qualifications and satisfy all requirements set forth in the IFB.
Payment will be made within thirty 30 days after satisfactory acceptance by the county of all completed services and receipt of a valid invoice, in accordance with the texas governmentcode, chapter **** will be made within thirty 30 days after satisfactory acceptance by thecounty of all completed services and receipt of a valid invoice
Criteria utilized by guadalupe county for determining the lowest responsible bidder includes, but is not limited to, bidder meeting the countys published specifications, biddersexperience, skill, ability, business judgment, financial capacity, possession of the necessary facilities orequipment, previous performance, reputation, promptness, and any factor which could reasonably beasserted as being relevant to successful performance. criteria utilized by guadalupe county for determining the lowest responsible bidder includes, but is not limited to, bidder meeting the countys published specifications, biddersexperience, skill, ability, business judgment, financial capacity, possession of the necessary facilities orequipment, previous performance, reputation, promptness, and any factor which could reasonably beasserted as being relevant to successful performance.
To be considered for this purchase, your firm must meet the qualifications and satisfy the requirements set forth in the ifb. to be considered for this purchase, your firm must meet the qualifications and satisfy the requirements set forth in the ifb.
Liquidated damages for delay in completion are five hundred dollars **** per calendar day. liquidated damages of five hundred dollars **** per calendar day in the event of its failure to complete work inaccordance with the schedule set forth in the agreement.
Any sample with percent air voids of more than 10 or less than 2 will be rejected. any sample with percent air voids of more than 10 or less than 2 will be rejected.
Protests before award must be submitted in writing to the purchasing agent not later than six 6 calendar days after bid opening. protests before award must be submitted in writing to the purchasing agent notlater than six 6 calendar days after bid opening,
Incomplete bid submissions all requested required documents signatures will be considered nonresponsive and will be rejected. incomplete bid submissions all requestedrequireddocumentssignatures will be considered nonresponsive and will be rejected.
The contract period is for one year effective the date commissioners courtawards the contract. the contract period is for one year effective the date commissioners courtawards the contract.
