The U. S. Embassy in Paris is seeking offers for the replacement of an air conditioning system. Proposals must be submitted electronically by February 23, 2026, at 16:00 local French time. A site visit is scheduled for February 3, 2026. Offerors must be registered in the SAM system. The contractor shall begin performance within 30 calendar days and complete it within 55 calendar days after receiving award, notice to proceed. The government intends to award a contract based on initial proposals, without holding discussions. The contract will be a firm fixed price contract.
The contractor shall complete the work within 55 calendar days after receiving award, notice to proceed.
Payments are subject to FAR ****, payments under fixed-price construction contracts.
The contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.
The government intends to award the contract to the lowest priced, technically acceptable offeror who is a responsible contractor.
Offerors must be technically qualified and financially responsible to perform the work described in this solicitation.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of 200 two hundred euros for each day of delay until the work is completed or accepted.
The embassy intends to conduct a site visit on February 3, 2026 at 14:30 local time.
Protests, as defined in section **** of the federal acquisition regulation, that are filed directly with an agency, and copies of any protests that are filed with the general accounting office gao, shall be served on the contracting officer.
It is anticipated that the range in price of this contract will be: between 100,000 and 250,000
