Concrete Vibrator Government Bids & RFPs

The anticipated start date, weather permitting, is August 10, 2026. The work shall be substantially completed as provided in article 2 of the general conditions and completed and ready for final payment in accordance with article 12 of the general conditions.

Owner shall make progress payments on account of the contract price on the basis of contractors applications for payment as recommended by engineer about 35 days after submittal of pay request by contractor. Progress payments will be made in accordance with state act 524.

The contractor warrants that they have not been influenced by an oral statement or promise of the owner or the engineer, but only by the contract documents.

In evaluating bids, the owner and engineer shall consider the qualifications of the bidders, whether or not the bids comply with the prescribed requirements, alternates, and unit prices, if requested in the bid forms, and any other consideration the owner or engineer deems pertinent.

The selected contractor must have at least 3- years of experience utilizing a vibratory augering and tampering over form riding paving machine.

Owner and contractor agree that as liquidated damages for delay but not as a penalty contractor shall pay owner, city of woodhaven, $1,000 for each day that expires after the time specified in paragraph 3. 1 for completion until the work is completed.

Before submitting a bid, each bidder must visit the site to familiarize itself with local conditions that may, in any way, affect cost, progress or performance of the work.

Failure to submit any such data within the five 5 day period shall give the owner and the engineer the right to finally reject the contractors bid.

The bid notice states that the delivery date or when work will start shall be stated in definite terms as they may be taken into consideration when making award. If requested, the delivery date or when work will start shall be stated in definite terms as they may be taken into consideration when making award.

The bid notice states that award shall be made to the lowest responsible bidders whose offer best responds to the quality, capacity, and service requirements of cole county, as determined by the county. Award shall be made to the lowest responsible bidders whose offer best responds to the quality, capacity, and service requirements of cole county, as determined by the county.

The county may make such investigations as deemed necessary to determine the ability of any respondent to provide the product and/or service described herein. cole county may make such investigations as deemed necessary to determine the ability of any respondent to provide the product andor service described herein.

The contractor will forfeit a penalty to the county of $100 per day or portion of the day for each worker that is paid less than prevailing rate for any work done under the contract by the contractor or by any subcontractor. he contractor will forfeit a penalty to the county of 100 per day or portion of the day for each worker that is paid less than prevailing rate for any work done under the contract by the contractor or by any subcontractor.

Respondents are advised that all questions concerning the meaning or intent of these specifications must be submitted in writing and received at least five 5 business days prior to the date scheduled for bid opening. espondents are advised that all questions concerning the meaning or intent of these specifications must be submitted in writing and received at least five 5 business days prior to the date scheduled for bid opening.

The bid notice states experience and necessary equipment will be a major factor in bid selection.