BidHits uses cookies to provide an individualized service and care for the privacy and protection of shared data.
By browsing this site, we understand that you agree to the terms of our Privacy Policy.
Custom Shoes Government Bids & RFPs
AI email alerts, regional filters, and access to bid documents
Our AI understands your business and finds more opportunities. - 14-day free trial - no auto-charge.
90% recommend BidHits (968 real users, 11/18/2025).Methodology
USA | CA | LOS ANGELES COUNTY | SAN PEDRO Small City
Design, construct and deliver four ( 4) monohull foam collar full- cabin outboard motor powerboat vessels
Design, construct and deliver four 4 monohull foam collar full cabin outboard motor powerboat vessels 1 Safe 33 full cabin. 4 2 Safe 33 full cabin specifications: 3 upgrade to stacked forward bow 4 storage/anchor lockers with topside access on safe 1 0 wide. 4 fritted window package on safe large fc. 4 5 add custom sbi fabricated aft cabin 4 workstation w 1 chart light 1 110vac outlet on safe fc. 6 allsalt adjustable footrest w 20 tread, 6 8 height adjustment, 0 deg incline mounted. 7 black rubstrake 4 8 collar color black 4 8 safe 1 oft beam boats personnel recovery 4 cutout. 9 black rubberized rail wrap 4 10 black rubberized dash skid 4 11 antifouling bottom paint, black, on safe 33 4 fc. 12 gray painton nonskid deck coating on 4 safe **** tow spool w 300 line, hand brake cover. 4 14 110vac shore power kit w generator 5 4 battery system wchargers 15 kohler 6kw 6ekod 60hz diesel generator w 4 10 gal diesel tank in aft lockers on safe 10 wide. 16 upgrade to dr led kevin 600 lumens led 4 flood lights. 17
AI helper
The bid is for the design, construction, and delivery of four monohull foam collar full cabin outboard motor powerboat vessels. Bidders must submit all requested quotation documents. The bid is due before 11:00 a. m. on December 2, 2025. The contract will be executed by the Executive Director on behalf of the Harbor Department of the City of Los Angeles. The Harbor Department may issue addenda to modify or cancel the bid request. The vendor must provide a production schedule within 21 days of the contract award. The vendor must notify George Cummings not less than ten days in advance that the vessel is ready for final inspection and sea trials. The vendor must include a copy of the freight bill with the invoice. The Harbor Department is exempt from federal excise taxes. Bidders must submit CEC Forms 50 and 55. The Harbor Department has a Local Business Preference Program (LBPP). The equipment and materials furnished shall be new and unused. The equipment must be completely serviced locally by the vendor prior to delivery. The vendor shall comply with all applicable ordinances, laws, rules, and regulations. The contract may be terminated for convenience with 30 days' notice. The bid is subject to acceptance by the department for a period of three months.
The bid notice states that within 21 days of award of contract, the contractor shall provide a production schedule and delivery date. Within 21 days of award of contract, contractor shall provide a productionschedule and delivery date.
The bid notice states that payment terms are net 30 days unless the contractor quotes otherwise. Payment terms are net 30 days unless contractor quotes otherwise.
The bid notice states that the terms of warranty on new materials offered are free parts and service labor for defective materials and workmanship for the following time period after goods and/or work have been accepted: parts: labor: erms of warranty on new materials offered. free parts and service labor fordefective materials and workmanship for the following time period after goods andor work have beenaccepted: parts: labor:
The bid notice states that the department may make a combined award of all items complete to one bidder or may award separate items to various bidders. The department maymake combined award of all items complete to one bidder or may award separate items to variousbidders.
The bid notice states that an approved AA plan or certification, if not on file, will be required prior to award of contract. affirmative action an approved aa plan or certification, if not on file, will be required prior to award of contract.
The bid notice states that should the achievement of any milestone or delivery fall behind schedule by more than 90 days, such delay shall be an event of default, and the city shall have the right to terminate this contract without compensation to the contractor. should the achievement of any milestone or delivery fall behind schedule by more than 90 days, suchdelay shall be an event of default, and the city shall have the right to terminate this contract without compensation to the contractor.
sCMOS Cameras for the HSX Spectrometer ( 2026- UWMSN- ****- RFB) - The University of Wisconsin- MADISON is requesting bids for the purchase of sCMOS Cameras for the HSX Spectrometer ( ShopUW+ Event Number 2026- UWMSN- ****- RFB) . Information for this solicitation can be found and responses MUST be entered online at: www. ***. *. * CustomerOrg= UWisconsin . If you have any questions, they MUST be directed to: Eric Thompson E- mail: ***@***. *. *
Request for Information - Open- Source Customer Relationship Management ( CRM) - See attached RFI. Companies who wish to respond to this RFI should send responses via email no later than December 5, 2025 at 11: 00AM ET to ***@***. *. * ( cc: ***@***. *. *). All responses shall be subm
Print Shop Specialty Paper - The Statewide Procurement Division ( SPD), a division of CPA, requests sealed responses for Print Shop Specialty Paper. A major customer for this item is the Texas Department of Criminal Justice ( TDCJ).
****- 002 Jones & Bartlett Learning Materials - BridgeValley Community and Technical College Request for : ****- 002/Jones & Bartlett Learning Materials Any questions should be directed to: ***@***. *. *
learning materials published by jones bartlett learning, llc jbl supply official jbl materials, including textbooks, ebooks, access codes, instructor resources, and custom course bundles as requested by the college. provide competitive institutional pricing, with preference given to bids offering a discount comparable to or better than the 25 discount available through direct purchase from jbl. ensure timely fulfillment and delivery of all materials in the quantities, formats, and timeframes specified by the college, coordinating as needed with the colleges ecampus bookstore partner. offer customization options for programspecific book bundles to align with facultyselected course materials and curriculum requirements. support multiple departments and instructional sites under this contract, coordinating orders, billing, and delivery with the colleges designated representatives. provide reporting and order documentation upon request, including details on pricing, quantities, and delivery schedules. maintain co
AI helper
The college is seeking bids from qualified vendors to provide learning materials published by jones bartlett learning, llc jbl. Proposals must be received by the colleges office of fiscal affairs prior to the date and time specified in section 1. 2, schedule of events. All inquiries regarding the specifications or proposal submission must be submitted in writing, by the question deadline, to: justa atha, ***@***. *. * subject line of all communications must reference: rfp bv2526002. The college shall select the best value solution according to the criteria considered for contract award. Invoices will be submitted in arrears and are typically paid within a thirty 30 day timeframe. The initial term of the contract shall be for one 1 year from the date of full execution. The contract may be renewed annually, for up to two 2 additional oneyear terms, by mutual written agreement of both parties. Respondent must assign qualified personnel with demonstrated experience in the procurement, distribution, and support of educational materials, specifically those published by jbl.
The bid notice states ensure timely fulfillment and delivery of all materials in the quantities, formats, and timeframes specified by the college, coordinating as needed with the colleges ecampus bookstore partner.
The bid notice states invoices properly prepared and submitted in accordance with the terms and conditions of the contract are typically paid within a thirty 30 day timeframe.
The bid notice states he cfocpo will perform a final review and award based upon the overall services, qualifications, respondent preference, if applicable and cost.
The bid notice states espondent must assign qualified personnel with demonstrated experience in the procurement, distribution, and support of educational materials, specifically those published by jbl.
Set it and forget it: enable government bid alerts in 3 steps
1
Choose the keywords
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Sign up and receive by email
Start the 14-day free trial and receive alerts with links to bid documents or the official posting.
3
Adjust if needed
Add or edit keywords, set regions, choose your email delivery schedule and email style. Map view available in the dashboard.
What our users say
90% recommend BidHits (968 real users, 11/18/2025).Methodology
All bids related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the bid documents.
R. M. Ferreira
It is complete and optimal, it improves my time.
R. de L. Cruz
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good — I find exactly what I’m looking for. It’s a great experience.
G. Sigrist
I’m notified immediately about every bid that opens in my area. It really helps my work.
E. Goncalves
A complete, easy-to-use system. Support from calm, patient, and clear-teaching professionals.
We selected the most helpful reviews from real users. Order may change periodically.
I don’t look for tenders—they find me!
G. Moura
Simple, easy to use, and always up to date.
J. Z. Abi-zaid
Easy to find the bids.
R. M. David
Great recommendations appear. Having the bid process link right in the email body helps a lot and saves time.
V. Kafka
With the chosen keywords, I can find many bids of interest! I learn about new notices well in advance, giving me enough time to get organized to participate.
D. Comaq
The system is very practical. It’s helped increase my monthly revenue.
F. H. Silva
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
O. O. Padron
I’m satisfied with the direct access to bids.
J. S. Santos
Receiving notifications saves a lot of time wasted searching for ongoing bidding notices.
A. S. Integradas
Provides information about bidding in a simplified, clear and objective way.
G. A. B. Dos Santos
Your search service has helped me a lot, improving the results of our contracts.
BidHits is a public bid search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the bid list becomes limited and you won't be charged automatically.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the bids panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see bids by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query contracts via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals every day at the federal, state, and local levels. Bid notices are added to the system as soon as they are published on the source portal.
Plans start at $ 39.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access bid documents or the official posting, and filter by region and method.
Transcript
Welcome to BidHits. Start by adding a few key words. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the bid...
Loading summary...
Methodology
Unaided survey with 968 active users, conducted through 11/18/2025.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
