Request for quotes (RFQ) for repair of underground storage fuel tank and manholes at the U. S. Embassy in Bangkok, Thailand. The U. S. Government intends to award a contract to the responsible company submitting an acceptable offer at the lowest price. A mandatory site visit is scheduled for June 5, 2026. Questions are due by June 9, 2026. Quotations are due by June 22, 2026, and must be submitted electronically in English. Offerors must be registered in the SAM system. The contract type will be firm-fixed price with a duration of 30 calendar days. All work must comply with relevant U. S. and international standards. A one-year warranty is required for all installed systems, materials, and workmanship.
The entire work must be completed and ready for use no later than 30 days after NTP issuance. The contractor shall be required to: . . . c complete the entire work ready for use not later than 30 days after ntp issuance.
Requests for payment may be made no more frequently than monthly, covering the value of labor and materials completed and in place. The payment determination is made by the contracting officer after inspection. The 14-day payment period is changed to 30 days. Requests for payment, may be made no more frequently than monthly. . . . under the authority of ****, the 14 day period identified in far ****1ia is hereby changed to 30 days.
All installed systems, materials, and workmanship shall be warranted for one year from final acceptance. The contractor must promptly correct any defects during this period. in the event the contractor complies with the scope of work, all installed systems, materials, and workmanship shall be warranted for one 1 year from final acceptance.
The U. S. Government intends to award a contract to the responsible company submitting an acceptable offer at the lowest price. he u. s. government intends to award a contract purchase order to the responsible companysubmitting an acceptable offer at the lowest price.
Offerors shall be registered in the SAM system for award management database prior to submittal of their offer/proposal. offerors shall be registered in the sam system for award management database athttps:www. sam. gov prior to submittal of their offerproposal as prescribed under far ****.
If the contractor fails to complete the work within the time specified, they shall pay liquidated damages of 3,000 Baht for each calendar day of delay. if the contractor fails to complete the work within the time specified in the contract, or any extension, the contractor shall pay liquidated damages to the government in the amount of3, 000 baht for each calendar day of delay until the work is completed or accepted.
The site visit is mandatory and has been scheduled for June 5, 2026, at 10:30 am at **** Wireless Rd. , Lumpini, Pathumwan, Bangkok, Thailand ****. he site visit is required and has been scheduled for june 5, 2026 at 10: 30 am at **** wireless rd.
Failure to be registered in the SAM system at the time of proposal submission may deem the offeror's proposal nonresponsive. failure to be registered at time of proposal submission may deem the offerors proposal to beconsidered nonresponsive and no further consideration will be given.
