This is a solicitation for a firm-fixed-price construction contract for Space Launch Delta 45, Patrick Space Force Base, FL. The project involves repairing and renovating PMEL, Bldg 981, including replacing all air handling units and associated control systems, and establishing HVAC emergency shutoff. The magnitude of the project is between $1M and $5M. This acquisition is a Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside. Bids are due by April 1, 2026, at 10:30 AM EST. Bid opening will occur on April 1, 2026, at 11:00 AM EST. A mandatory site visit is scheduled for February 10, 2026, at 10:30 AM EST. Electronic bids are required and must be submitted by the closing date and time to the specified email addresses. Additional documents required include SF ****, Section B with proposed total price, bid guarantee, completed Section K, cost estimate breakdown, and SDVOSB self-performance worksheet. Funds are not presently available for this project.
The contractor shall begin performance within 30 calendar days and complete it within 365 calendar days after receiving award, notice to proceed. The period of performance for this project is 365 calendar days including non-access days beginning at NTP.
The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.
The contract includes FAR clause ****, Warranty of Construction.
The government intends to make a single award to the responsible bidder conforming to the invitation for bid, which will be the most advantageous to the government, considering only price.
This acquisition is being issued as a Service-Disabled Veteran-Owned Small Business (SDVOSB) set aside. Offerors not meeting this criteria will be deemed nonresponsive and ineligible for award.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of **** for the first calendar day of delay and an amount of **** for each subsequent day until the work is completed or accepted.
A site visit has been arranged for February 10, 2026, at 10:30 AM EST. Attendees must sign in at the visitor center at least 20 minutes prior to the site visit and will be escorted to the site.
The magnitude of this project is between $1M and $5M.