Bar Renovation Government Bids & RFPs

All work must be completed within 120 calendar days after notice to proceed. The contract completion is within 120 calendar days after ntp.

Payment terms are those established by the contract. No prompt payment discount is offered. Payment terms are those established by the contract.

The proposal includes a five-year glazing material warranty and a one-year overall construction warranty. provide the specified fiveyear glazingmaterial warranty and oneyear overall construction warranty.

The offeror is a service-disabled veteran-owned small business with federal, state, municipal, military, educational, and commercial experience. servicedisabled veteranowned small business and experienced ballistic window, doors, glazing contractor.

The total proposed price is $84,**** proposed price 84, ****

Responses must be received by 12:00 pm central on October 5, 2026 via email to the contracting officer at ***@***. *. * must be received by 12: 00 pm central on october 5, 2026

Selection based on demonstrated competence and qualifications. firms will be selected for negotiation based on demonstrated competence and qualifications for the required work

Must be certified SDVOSB in SBA database. only businesses listed as certified in the sba certification database at https:veterans. certify. sba. gov, shall be considered

The most highly rated firm must physically come to the site. the most highly rated firm must physically come to the site and review the project before submitting a price proposal

Failure to provide certification may result in ineligibility. the government will not consider offers for award from offerors that do not provide the certification, and all such responses will be deemed ineligible for evaluation and award

The entire work must be completed within 60 consecutive calendar days. the entire work for this contract shall be completed within sixty 60 consecutive calendar days.

Monthly invoices are submitted, with payment anticipated within 15 days after the supervising professional's certificate. the city will then, following the receipt of the supervising professionals certificate, make payment to the contractor as soon as feasible, which is anticipated will be within 15 days.

The contractor guarantees the quality of work and all equipment and materials for one year. the contractor shall guarantee the quality of the work for a period of one year.

Bidders must provide qualifications, experience, references, safety program, EMR, and workforce development documentation. qualifications and experience of the bidder and of key persons, management, and supervisory personnel to be assigned by the bidder.

Liquidated damages of $1,000 per calendar day for delay. an amount equal to 1, 000 for each calendar day of delay in the completion of all the work.

A preproposal conference is held at the site, and attendance is highly recommended. a preproposal conference for this project will be held on tuesday, october 6, 2026 at 10: 00am at cobblestone farm barn at **** packard st, ann arbor, mi ****.

Proposal protests must be filed within 5 business days of any notice of intent. all proposal protests must be in writing and filed with the purchasing manager within five 5 business days of any notices of intent.

Failure to provide bid security or required forms may result in disqualification. proposals that fail to provide a bid security upon proposal opening will be deemed nonresponsive and will not be considered for award.