Respondents must include all required documents with their response. Respondents must upload their response to nttas marketplace no later than the date and time identified as the response due date. Alternatively, a physical response may be submitted to the above address. When responding, be certain to check the confidential check box for each uploaded document. A virtual prebid conference will be held on november 10, 2025 at 2: 30 pm ct. Submit questions via www. ***. *. *
The work to be performed under this contract shall be completed in full in 300 calendar days from the date of the notice to proceed. The work to be performed under this contract shall be completed in full in 300 calendardays from the date of the notice to proceed.
The bidder shall procure a warranty bond in the amount of twenty five percent 25 of the value shown in the total bid amount for a period of 2 years to insure and guarantee the repair andor replacement of any items furnished by the contractor in this contract discovered to be defective in materials andor workmanship following the date of final acceptance. he bidder shall procure a warranty bond in the amount of twenty five percent 25 of the value shown in the total bid amount for a period of 2 years to insure and guarantee the repairandor replacement of any items furnished by the contractor in this contract discovered to bedefective in materials andor workmanship following the date of final acceptance.
The contract will be awarded to the lowest responsible bidder. tta or designated representative will award the contract to the lowest responsible bidder as determined in accordance with article 2. 11, tabulating bids.
The bidder must be capable of performing each of the various items of the work for which a bid is submitted. The bidder must be capable of performing each of the various items of the work for which a bid is submitted.
The charge that the contractor shall pay for each calendar day that it is in default on time to complete the work shall be onethousand five hundred dollars 1, **** per calendar day. in conformity with article 8. 6, failure to complete work on time, of the standardspecifications, as modified by the special provisions and special specifications, the charge thatthe contractor shall pay for each calendar day that it is in default on time to complete the workshall be onethousand five hundred dollars 1, **** per calendar day.
A virtual prebid conference will be held on november 10, 2025 at 2: 30 pm ct. a virtual prebid conference will be held on november 10, 2025 at 2: 30 pm ct. , refer to solicitation for link details.
Submit questions via www. ***. *. * questions via www. ***. *. *
