Eva Government Bids & RFPs

The bid notice states that proposals must be submitted o later than 3 4 2026, 2: 00 p. m. exactly Pacific local time.

The bid notice states that questions due by 2 25 2026, 5: 00 p. m.

The bid notice states that he anticipated maximum total compensation to the consultant for services under the awarded agreement will not exceed 115, 000 for the duration of the agreement period, unless amended.

The contractor must commence work within two 2 weeks upon issuance of a notice to proceed. he contractor must commence work within two 2 weeks upon issuance of a notice to proceed.

Payment terms and invoicing requirements shall be as defined by the agreement form. payment terms and invoicing requirements shall be as defined by the agreement form.

The contractor agrees to warrant and correct any defective or faulty work or material that may appear within 1 one year after completion of the work and receipt of final payment. he contractor agrees to warrant and correct any defective or faulty work or material that may appear within 1 one year after completion of the work and receipt of final payment.

Heard County reserves the exclusive right to determine which bidder should be awarded the contract. heard county reserves the exclusive right to determine which bidder should be awarded the contract.

All bidders must be prequalified and in good standing with gdot to perform the services as listed in this request for bids. all bidders must be prequalified and in good standing with gdot to perform the services as listed in this request for bids.

The contractor shall pay the owner the sum of 500 per day for each and every calendar day of unexcused delay in achieving substantial completion of the project beyond the date set forth in the contract documents for substantial completion. he contractor shall pay the owner the sum of 500 per day for each and every calendar day of unexcused delay in achieving substantial completion of the project beyond the date set forth in the contract documents for substantial completion.

All questions concerning this rfb must be submitted in writing email is preferred but fax andmail may be used to the program manager no later than 12: 00 pm on february 25, 2026, localtime. all questions concerning this rfb must be submitted in writing email is preferred but fax andmail may be used to the program manager no later than 12: 00 pm on february 25, 2026, localtime.

The bid notice states that he respondent must receive a score of 70 points of the total 100 points reflected in section 2. 1, to receive an award.

The bid notice states that espondents must demonstrate they are an authorized manufacturer or distributor by providing the information requested.

The bid notice states that 4 for 5 years will receive 2 points deduct . 5 for each year less than 5.

The bid notice states that espondents may appeal the award decision by submitting a written protest to the university of maine systems university of maine systems executive director of strategic procurement and chief procurement officer within five 5 business days of the date of the award notice.

The bid notice states qualification statements must be received by the township no later than the due date.

The township will consider qualification statements only from firms, individuals, or organizations that, in the townships judgment, have demonstrated the capability and willingness to provide high quality services to the taxpayers of the township in the manner described in this rfq.

The township seeks qualification statements from respondents that have expertise in the provision of legal services.

The respondent acknowledges that the services rendered may not exceed **** per hour.