The contract is for providing safe and operational vehicles for USACE personnel in Israel. The contract duration is 12 months with a possible 6-month extension. The contractor must provide vehicles meeting specific requirements, including insurance, and coordinate delivery with the COR. The contractor must also provide a replacement vehicle within 3 hours. The contractor must provide a signed letter of conformance. The contractor must provide a contact list within 7 days after contract award. The contractor must provide vehicle breakdown recovery service and roadside assistance within 3 hours, 24 hours a day, 7 days a week throughout israel. The contractor and the COR shall perform a joint inspection prior to accepting a vehicle from the contractor and prior to the contractor accepting the vehicle from the government. Any damage shall be documented by photographs and in writing and shall include the date of the inspection and signatures of the individuals performing the inspection. The report shall be submitted to the cor and contracting officer within 10 calendar days after the inspection.
The contractor shall deliver all vehicles on the first day of the period of performance as specified in paragraph 1. 4 of this PWS, which is December 10, 2025. The contractor shall deliver all vehicles on the first day of the period of performance as specified in paragraph 1. 4 of this pws.
Invoices will be handled in accordance with the prompt payment act 31 **** and office of management and budget omb prompt payment regulations at 5 cfr part **** will be handled in accordance with the prompt payment act 31 **** and office of management and budget omb prompt payment regulations at 5 cfr part ****.
The contractor shall provide, at no additional cost to the government, the repair or replacement of all fair wear and tear parts. The contractor shall provide, at no additional cost to the government, the repair or replacement of all fair wear and tear parts.
The contractor shall employ persons with the ability to fluently speak, read, write, and understand english to interact with usg personnel. The contractor shall employ persons with the ability to fluently speak, read, write, and understand english to interact with usg personnel.
Any penalties due to late payment as a result of delay on the part of the contractor in forwarding these tickets or delay in converting any fleet vehicle tickets to private tickets shall be borne by the contractor. Any penalties due to late payment as a result of delay on the part of the contractor in forwarding these tickets or delay in converting any fleet vehicle tickets to private tickets shall be borne by the contractor.
