Roofing Shingles Government Bids & RFPs

The awarded vendor is expected to complete all aspects of this project by April 30, 2026.

All parts and labor related to contracts must be guaranteed and include a 12month warranty from the date of acceptance by the city.

This solicitation shall be awarded to the lowest responsible bidder.

Respondents must have a valid connecticut business license throughout the solicitation process.

If the contractor fails to achieve substantial completion or final completion, as applicable by the dates specified in the contract including any change orders or approved extensions, the contractor shall pay to the city liquidated damages in the amount of 1,000 for each calendar day of delay beyond the contract time until the work is complete and accepted.

A mandatory walkthrough of site is required.

Any solicitation protest must be submitted in writing.

The contractor shall commence and complete the work under the ensuing contract on dates to be specified within the notice to proceed. Firm start and completion dates will be determined during the preconstruction conference.

The MPHA is responsible for making progress payments. Typically, progress payments for acceptable work and materials delivered and stored on the site will be made at 30day intervals.

All work provided by any contractor shall be warranted or guaranteed by that contractor for a period of time of not less than five 5 calendar years and a manufacturers 30year ndl full system warranty from the date of substantial completion.

The MPHA intends to retain a contractor pursuant to a low bid basis, also taking responsiveness and responsibility into consideration.

The MPHA will evaluate each bid submitted as to responsibility e. g. a firm that is qualified, responsible and able to provide the required services to the MPHA.

The successful bidder shall agree to pay as liquidated damages the amount of **** for each consecutive calendar day for which the work is not complete, beginning with the first day beyond the completion date stated on the notice to proceed.

The scheduled prebid conference identified on page 2 of this document is, pursuant to hud regulation, not mandatory although highly recommended.

Questions shall be submitted online in the housing agency marketplace or via email to the buyer by the date and time noted above.

The work shall be completed within seventy-five 75 days of the start date. Work shall be completed within seventyfive 75 days of the start date.

The contractor shall warrantee work to be free of defects and workmanship for a period of one 1 year from date of acceptance. he contractor shall warrantee work to be free of defects and workmanship for a period of one 1 year from date of acceptance.

The government intends to make an award based on which offeror provides the best value to the government considering and comparing the past performance and price of each remaining offeror. The government will consider volume ii past performance and volume iii price in this tradeoff process.

Offerors are required to be SDVOSB certified with the Small Business Administration (SBA). Offerors are required to be sdvosb certified with the small business administration sba.

A site visit shall be held on January 20, 2026, @10:00am CST. site visit shall be held on january 20, 2026, @10: 00am cst.

The magnitude of the construction project is between 1, 000, 000 and 2, 000, 000. he magnitude of the construction project is between 1, 000, 000 and 2, 000, 000