Boat Maintenance Government Bids & RFPs

The bid notice states that the period of performance is from December 16th through December 18th 2025.

The bid notice states that proposals must include payment terms.

The bid notice asks to please provide any warranty information.

The bid notice states that award of a contract will be based on the following criteria: the purchase order will be awarded as a firm fixed price contract using simplified acquisition procedures in accordance with far part 13.

The bid notice states that vendors must be registered in www. ***. *. *

The project must be completed by August 31, 2026. contractor shall begin work upon notice of award with all services for the project to be completed by august 31, 2026.

Payment will be made within 30 days after receipt of a properly prepared invoice or the receipt and acceptance of services ordered, whichever is later. payment normally will be made to the contractor within thirty 30 days after receipt of a properly prepared invoice, or the receipt of and acceptance of services ordered, whichever is later.

The award will be made to the respondent whose quote is considered to be the best value to TPWD, price and other factors considered. pwd will award a contract to the respondent whose quote is considered to be the best value to tpwd, price and other factors considered.

The awarded contractor shall meet the following minimum qualifications: shall have been engaged in the business of providing the specified services for a minimum of three 3 years. a shall have been engaged in the business of providing the specified services for a minimum of three 3 years.

If delay is foreseen, the contractor shall give written notice to TPWD. Default in promised completion without accepted reasons or failure to meet specifications authorizes TPWD to purchase services elsewhere and charge any increased costs for the services, including the cost of resoliciting, to the contractor. if delay is foreseen, contractor shall give written notice to the tpwd. default in promised completion without accepted reasons or failure to meet specifications authorizes the tpwd to purchase supplies elsewhere and charge full increase, if any, in cost and handling to defaulting contractor.

Bidders are highly encouraged to attend a site visit to inspect the work site to become familiar with the condition and equipment needed to conduct the requested services. bidders are highly encouraged to attend a site visit to inspect the work site to become familiar with the condition and equipment needed to conduct the requested services.