Power Plant Government Bids & RFPs

The bid notice states that the completion date is May 12, 2026, or as mutually agreed upon. Tentative start date of May 4, 2026 and completion date of May 12, 2026, or as mutually agreed.

The bid notice mentions that before the final payment may be made, the contractor shall furnish a written clearance from the commissioner of labor of the state of Nebraska, certifying that all payments then due of contributions or interest which may have arisen under the contract have been made by the contractor or his subcontractors to the unemployment compensation fund. Before the final payment may be made, the contractor shall furnish a written clearance from the commissioner of labor of the state of Nebraska, certifying that all payments then due of contributions or interest which may have arisen under the contract have been made by the contractor or his subcontractors to the unemployment compensation fund.

The bid notice states that the contractor shall be required to furnish a performance, payment and maintenance bond in a sum equal to one hundred percent 100 of the contract price, for a period of one 1 year past the completion of the project. The contractor shall be required to furnish a performance, payment and maintenance bond in a sum equal to one hundred percent 100 of the contract price, for a period of one 1 year past the completion of the project.

The bid notice states that the city of Fremont hereby reserves the right to accept that bid which, in its judgment, will produce the best job of workmanship and material, whether or not it is the lowest bid. The city of Fremont hereby reserves the right to accept that bid which, in its judgment, will produce the best job of workmanship and material, whether or not it is the lowest bid and reserves the right to reject any or all bids and to waive any or all informalities of any proposal.

The bid notice states that any bids received from contractors not so qualified will be returned unopened. Any bids received from contractors not so qualified will be returned unopened.

The bid notice states that failure to submit an acceptable affirmative action statement and program within the time allotted shall result in the forfeiture of the bidders bond. Failure to submit an acceptable affirmative action statement and program within the time allotted shall result in the forfeiture of the bidders bond.

The response date for this sources sought notice is March 26, 2026.

The bid notice asks for information regarding company size status as listed in SAM under NAICS code ****, and if the company is verified as a Service Disabled Veteran Owned Small Business (SDVOSB) or Veteran Owned Small Business (VOSB). It also inquires about experience working with government agencies and demonstrating experience with operating, monitoring, maintaining, repairing, and supporting mission-critical infrastructure systems for government facilities. Additionally, it asks if the company has certified and trained personnel to operate and maintain systems such as HVAC, fire alarm control panels, emergency power generators, and SCADA/BMS control systems.