Services Government Bids & RFPs

Bids must be received electronically on or before 2:00 p. m. Mountain Time MT Thursday, July 30, 2026.

The city will award the contract to the lowest responsible bidder who, in the city's judgment, will best serve the city's interests.

The bidder is responsible to be informed of, and the bidder awarded the contract shall comply with, all federal, state, and local laws, statutes, and ordinances relative to the execution of the work.

In the event the contractor fails to complete the work within the time limit set forth in the contract documents, liquidated damages shall be paid at the rate of one hundred dollars **** per day until substantial completion.

A mandatory pre-bid conference will be held on Friday, July 6, 2026, at 10:00 am at Police Courts, 810 E 10th Street, Loveland, CO **** will not be accepted from bidders who do not attend.

A single proprietary interest shall not submit multiple bids for the same work even though the individual bids are submitted under different names. The city reserves the right to reject all bids so submitted. Multiple submittals by a single proprietary interest may subject that company to removal from the city's list of eligible bidders.

Consultant may submit periodic invoices, which shall be paid by the town within 30 days of receipt.

Consultant hereby warrants that it is qualified to assume the responsibilities and render the services described herein and has all requisite corporate authority and professional licenses in good standing, required by law.

Consultant hereby warrants that it is qualified to assume the responsibilities and render the services described herein and has all requisite corporate authority and professional licenses in good standing, required by law.

If consultant proceeds without written authorization for a change in the scope of services, consultant shall be deemed to have waived any claim for additional compensation.

Consultants must have an established satisfactory record of performance for a reasonable period and sufficient financial support, equipment, and organization to satisfactorily execute the services if awarded an agreement.

A mandatory pre-submittal conference is required. if mandatory, a representative of the proposer must attend this conference to qualify to respond to this solicitation.

Proposers who fail to arrive prior to the scheduled starting time for the mandatory pre-submittal conference shall be considered nonresponsive and ineligible for award. Contacting the requesting department may result in disqualification.

The project must be substantially completed by August 9, 2026, as the **** academic year begins on August 10, 2026. all four 4 district schools must be fully completed with substantial project completion achieved no later than august 9, 2026.

Payments will be based on ninety percent (90%) of the total value of work completed and material in place, less all previous payments. Five percent (5%) retainage will be withheld until final acceptance. Payments will be based on ninety percent 90 of total value of work completed and material in place as mutually agreed upon, less allprevious payments.

The contractor shall guarantee all materials, workmanship, and satisfactory operation of all equipment for a period of one (1) year from the date of final acceptance. The contractor shall guarantee all materials, workmanship and the satisfactory operation of all equipment installed andor finished, for a period of one 1 year from the date of the final acceptance of the entire work

Awards will be made to the lowest qualified, responsible bidder. Awards will be made to the lowest qualified, responsible bidder.

Any bidder may be required to furnish evidence satisfactory to the district that they and their proposed subcontractors have sufficient means, experience, and required licenses in the types of work required. Any bidder may be required to furnish evidence satisfactory to the district that they and their proposed subcontractors have sufficient means, experience, and required licenses in the types of work required to assure completion of the contract in a satisfactory manner.

If work is not completed by the specified completion date, there shall be deducted from the amount due the contractor, as liquidated damages, the sum of $1,**** for each calendar day beyond the specified completion date. if, in the districts judgment work is not completed by the specified completion date there shall be deducted from the amount due the contractor, as liquidated damages accruing to the district, the sum of 1, **** for each calendar day, per project, beyond the specified completion date until work is completed.

A mandatory pre-bid meeting is scheduled for Monday, June 29th, 2026, at 8:00 am at Facilities, **** 5th Ave, Greeley, CO **** meeting: mandatory date: monday, june 29th, 2026, at 8:00am place: facilities **** 5th ave greeley, co ****

Unauthorized conditions, limitations, or provisions attached to the bid shall be cause for rejection of the bid. The district reserves the right to reject any bid from any contractor deemed unqualified. Unauthorized conditions, limitations, or provisions attached to the bid shall be cause for rejection of the bid.

Bids are due July 9, 2026, at 11:00 AM local time. date due: july 9, 2026, at 11: 00 am local time

The goal is to select the most capable supplier offering the most competitive price. he goal is to select the most capable supplier offering the most competitive price.

Bidders must be properly licensed and meet qualifications indicated in the bidding documents. Macomb County may investigate bidder's ability to perform. bidders must be properly licensed under the state laws governing their respective trades. bidders shall meet qualifications indicated in the bidding documents.

A mandatory pre-bid meeting is scheduled for June 29, 2026, at 12:00 PM at the Macomb County Jail. his is a mandatory prebid meeting. the purpose of this meeting is to review the job location and bid specifications.

Attempting to contact a county department other than purchasing regarding current bids may be grounds for disqualification. any attempt to contact a county department, other than purchasing, regarding current bids may be grounds for disqualification as a supplier.