Product Government Bids & RFPs

The contractor shall begin performance within 10 calendar days and complete it within **** calendar days after receiving award, notice to proceed. The contractor shall begin performance within 10 calendar days and complete it within **** calendar days after receiving award, notice to proceed.

The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer. The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.

The award will be made with reasonable promptness to the responsible bidder submitting the lowest responsive bid in accordance with requirements and provisions herein. The award will be made with reasonable promptness to the responsible bidder submitting the lowest responsive bid in accordance with requirements and provisions herein.

All eligible contractors that are capable of successfully completing the work identified in the requirement can submit a bid. All eligible contractors that are capable of successfully completing the work identified in the requirement can submit a bid.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of contracting officer insert amount for each calendar day of delay until the work is completed or accepted. If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of contracting officer insert amount for each calendar day of delay until the work is completed or accepted.

No site visit will be coordinated for this requirement. o site visit will be coordinated for this requirement

All questions shall be in writing and submitted no later than 15 december 2025 10: 00 am. all questions shall be in writing and submitted no later than 15 december 2025 10: 00 am.

The magnitude of the requirement is between 5, 000, **** and 10, 000, ****. he magnitude of the requirement is between 5, 000, **** and 10, 000, ****.

The bid notice states, If the items required in the contract resulting from this solicitation are customarily warranted in the trade by a standard commercial warranty, such warranty shall be incorporated into this contract and thereby provided to the government at no additional cost.

Contractors other then the OEM and its only authorized US distrubitor NDI interested in submitting a proposal must provide in their proposal a signed and certified agreement with the OEM authorizing distribution of the required supplies.

The bid notice states delivery of mids wdl sf1 terminals at the earliest possible date is desired.

The bid notice states a successful operational assessment is a requirement for any contract award.

The bid notice states questions regarding this announcement shall be submitted in writing by email only to mr. damon griffin. . . all questions shall be submitted no later than 12 february at 12: 00 pm pacific daylight time pdt.

The bid notice states he government is contemplating multiple contract awards under this effort at an estimated dollar range for each of approximately 900 million.

The bid notice states deliveries are to be made between april 15, 2026 through august 15, 2026.

To be eligible to submit offers, potential contractors must meet the ams vendor qualification requirements established in accordance with far subpart 9. 2. For information about becoming a qualified bidder, please reach out to newvendor@usda. gov.