Recreational Government Bids & RFPs

Bids are due no later than 2:00 p. m. , October 23, 2026. The document states: bids are due and must be submitted on the attached bid form, attachments b, no later than 2:00 p. m. , october 23, 26, 2026.

The contract will be awarded to the lowest eligible and responsible bidder. The document states: the town of westerly will award the contract to the lowest eligible and responsible bidder based on the base bid total.

Bidders must demonstrate sufficient ability and experience. The document states: no award will be made to any bidder who cannot satisfy the owner that he has sufficient ability and experience in this class of work.

Liquidated damages apply for late completion. The document states: the bidder must further agree to pay as liquidated damages to the owner, the sum as specified in table a of the agreement for each consecutive calendar day thereafter.

A nonmandatory prebid walkthrough is scheduled. The document states: a nonmandatory prebid walkthrough will be held on october 13, 2026 at 3:00 p. m. site location: 15 church street, bradford, ri ****.

Questions must be received by October 13, 2026. The document states: questions regarding this solicitation must be emailed and received by the purchasing agent at ***@***. *. * no later than 12:00pm on october 13, 2026.

Conditional or qualified bids will not be accepted. The document states: conditional or qualified bids will not be accepted. any bid received after the time and date specified shall not be considered.

Statements of qualifications must be received by October 16, 2026, at 12:00 PM Eastern Time. All qualification packages must be received by: october 16th, 2026, at 12pm eastern time.

Respondents must be authorized to conduct business in Georgia and hold required professional licenses. The prime respondent and each subconsultant shall possess and maintain all professional licenses and registrations required by the state of georgia for the services each will perform.

There is no site visit or preproposal conference. There will not be a conference held for this solicitation.

Questions and requests for clarification must be submitted by October 9, 2026, at 12:00 PM Eastern Time. All questions and requests for clarification must be submitted through the questionandanswer function for this solicitation in bidnet direct no later than 12: 00 p. m. eastern time on october 9, 2026.

Late submissions will not be considered. Any soqs received after the stated time and date shall not be considered.

Substantial completion is required by July 19, 2019, as stated: substantial completion date: july 19, 2019.

Monthly estimates are due by the first Monday, with payments made within approximately 30 days after review, as stated: payments will be made within approximately thirty 30 days after review by the owner.

A minimum one-year warranty is required for all materials and workmanship, as stated: the contractor andor manufacturer shall provide a minimum of one 1 year warranty for all materials and workmanship.

The contract will be awarded to the lowest responsible bidder, as stated: award of contract will be made to the lowest responsible bidder.

Bidders must meet all state bidding requirements and provide references, as stated: bidders will be required to meet all state bidding requirements and submit the proposal forms, certification, references, and bid bonds.

Failure to provide required bonds within 5 days may constitute default, as stated: the failure of the successful bidder to supply the required bonds within five 5 days after the notice of award. . . shall constitute a default.

Bidders should visit the site to ascertain conditions, as stated: bidders should visit the site and take such other steps as may be reasonably necessary to ascertain the nature and location of the work.

Failure to furnish a bid guarantee may cause rejection, as stated: failure to furnish a bid guarantee in the proper form and amount by the time set for opening of bids may be cause for rejection of the bid.

Completion date is June 15, 2020. The construction timeline is March 2, 2020 to June 15, 2020. completion date: june 15, 2020

Monthly estimates may be presented by the first Monday of each month. Payments are made within approximately 30 days after review. payments will be made within approximately thirty 30 days after review by the owner

A minimum one-year warranty is required for all materials and workmanship. the contractor andor manufacturer shall provide a minimum of one 1 year warranty for all materials and workmanship

Award will be made to the lowest responsible bidder. award of contract will be made to the lowest responsible bidder, as determined by the board of commissioners

Bidders must meet all state bidding requirements and provide references. bidders will be required to meet all state bidding requirements

Failure to provide required bonds within 5 days constitutes default. the failure of the successful bidder to supply the required bonds within five 5 days after the notice of award. . . shall constitute a default

Bidders should visit the site to verify conditions. bidders should visit the site and take such other steps as may be reasonably necessary to ascertain the nature and location of the work

Failure to furnish a bid guarantee in proper form may cause rejection. failure to furnish a bid guarantee in the proper form and amount by the time set for opening of bids may be cause for rejection

Substantial completion is required by May 17, 2019. The work must commence by April 1, 2019, weather dependent, and continue with due diligence until full completion and acceptance. As stated: substantial completion date: may 17, 2019.

Monthly estimates may be presented no later than the first Monday of each month, with payments made within approximately 30 days after review by the owner. Final payment is made within approximately 30 days of final inspection and approval. As stated: payments will be made within approximately thirty 30 days after review by the owner.

The contractor and/or manufacturer must provide a minimum one-year warranty for all materials and workmanship. As stated: the contractor andor manufacturer shall provide a minimum of one 1 year warranty for all materials and workmanship associated with the project.

The contract will be awarded to the lowest responsible bidder whose bid conforms to the invitation. As stated: award of contract will be made to the lowest responsible bidder, as determined by the board of commissioners.

Bidders must examine all documents, visit the site, and verify conditions. Submission of a bid is presumptive evidence of site visit and familiarity with local conditions. As stated: submission of bid will be considered presumptive evidence that the bidder has visited the site.

Failure to provide required bonds within 5 days after notice of award constitutes default, and the owner may award to the next bidder or readvertise. The defaulting bidder may be charged the difference in bid amounts. As stated: a charge against the defaulting bidder may be made for the difference between the amount of the bid.

Bidders should visit the site to ascertain the nature and location of the work and local conditions. Failure to do so will not relieve bidders from responsibility for estimating properly. As stated: bidders should visit the site and take such other steps as may be reasonably necessary.

Bids submitted after the closing time will be returned unopened. Failure to furnish a bid guarantee in proper form and amount may cause rejection. Failure to list surety company on bid proposal is a nonresponsive bid. As stated: bids submitted after the closing time will be returned unopened.