The Texas General Land Office seeks a contractor for coastal construction services to protect and enhance the rookery island habitat in Laguna Vista Spoil Island, Cameron County, Texas. The project involves placing rubble mound structure, erosion control features, and sand fill. Proposals must be submitted by August 28, 2026, at 2:00 p. m. CT. The project is subject to nesting season restrictions. The award will be based on best value. A site visit is strongly encouraged before proposal submission.
The award will be made to the respondent that provides the best value to the state of Texas. the glo shall not be obligated to accept the lowest priced proposal but shall make an award to the respondent that provides the best value to the state of texas.
Respondents must meet minimum qualifications, including having been in the coastal construction business for a minimum of three years. respondent must have recently been in the coastal construction business for a minimum of three 3 years
Contractor shall be liable to the glo for liquidated damages of **** per day until the contractor achieves substantial completion. liquidated damages of **** per day until the contractor achieves substantial completion.
Respondents are strongly encouraged to visit the site before submitting a proposal. before submitting a proposal, respondent is strongly encouraged to visit the site
The deadline for submitting questions is August 21, 2026, at 5:00 p. m. CT. deadline for submitting questions august 21, 2026, at 5:00 p. m. ct
Failure to observe prohibited communications may disqualify the respondent. failure to observe this restriction may disqualify the respondent.
The approximate cost range for construction of the project is 3,331,**** to 3,664,****. the approximate cost range for construction of the project is 3, 331, **** 3, 664, ****.
