Hookup Government Bids & RFPs

A mandatory prebid conference is scheduled for 11:00am on wednesday, july 22, 2026, at the project site located at **** e. gibson road, woodland, ca ****.

The project will be awarded to the lowest price technically acceptable proposal. this project will be awarded to the lowest price technically acceptable lpta proposal.

All prospective offerors are urged and expected to inspect the site where the work will be performed. The site visit will be conducted on tuesday, 01 september 2026 at 10: 00 a. m. mountain standard time mst at bsfb.

Contractors must be actively registered in SAM and certified with SBA DSBS as an SDVOSB. Vendor quote may be considered non compliant and rejected if the contracting officer is unable to verify registration and sdvosb certification status.

A backup technical site visit is scheduled for August 20, 2026, at 10:00am ct. amendment **** is issued to announce a backup technical site visit on thursday, august 20, 2026 at 10: 00am ct for vendors unable to attend the originally scheduled site visit on august 19, 2026.

A vendor quote may be rejected if registration or SDVOSB certification cannot be verified. Vendor quote may be considered non compliant and rejected if the contracting officer is unable to verify registration and sdvosb certification status.

The state will incur no penalty for late payment if payment is made in 30 or fewer days from receipt of goods or services and an uncontested invoice. the state will incur no penalty for late payment if payment is made in 30 or fewer days from receipt of goods or services and an uncontested invoice.

Manufacturers standard warranty shall apply unless otherwise stated in the ifb. manufacturers standard warranty shall apply unless otherwise stated in the ifb.

The state reserves the right to make an award on the basis of best value or in any other combination that will serve the best interests of the state. the state reserves the right to make an award on the basis of best value or in any other combination that will serve the best interests of the state

In the event a successful respondent fails to perform services or complete the obligations under the contract in a timely manner, tjjd may require successful respondent to pay, as liquidated damages and not as a penalty, an amount equivalent to 2 of the total cost for services or obligations not completed as required by the contract per calendar day of delay. in the event a successful respondent fails to perform services or complete the obligations under the contract in a timely manner, tjjd may require successful respondent to pay, as liquidated damages and not as a penalty, an amount equivalent to 2 of the total cost for services or obligations not completed as required by the contract per calendar day of delay.

Samples, when requested, must be furnished free of expense to tjjd. samples, when requested, must be furnished free of expense to tjjd.

Late andor unsigned bids will not be considered under any circumstances. late andor unsigned bids will not be considered under any circumstances.