Quarter Government Bids & RFPs

Deliveries must be made within 30 days after receipt of order. delivery of all products within 30 days after receipt of order

The award will be made to the responsible quoters providing the best value to the government based on the following factors: price: evaluated for fairness and reasonableness. past performance: evaluation includes prior experience and similar performance history. the contracting officer co will consider late deliveries, missing items, and frequent substitutions. delivery: a documented history of on time deliveries and reliability will be considered.

Quoters must include their unique entity identifier uei. all vendors must be active in sam. gov at the time of quote, award, and through final payment.

Failure to deliver within the established time frame will be considered as nonconformance to the terms of the contract. failure to deliver within the established time frame will be considered as nonconformance to the terms of the contract.

Contractor failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractors history of past performance. contractor failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractors history of past performance.

Delivery is required on or before **** unless special instructions are stated in the specifications. delivery to fci otisville by **** unless special instructions stated in the specifications

Awards will be made to the responsible quoters whose quote conforms to the requirements and is determined to provide the best value to the government, considering the evaluation factors outlined below. awards will be made to the responsible quoter s whose quote conforms to the requirements and is determined to provide the best value to the government

The government will evaluate the quoters past performance on a go no go basis, based on timeliness of deliveries and order accuracy and completeness. the government will evaluate the quoters past performance on a go no go basis

Failure to deliver by the requested deadline shall result in a cancelation of the order unless negotiated with the co cor. failure to deliver by the requested deadline shall result in a cancelation of the order unless negotiated with the co cor.

A history of substantial delivery delays or a pattern of incomplete or inaccurate deliveries will result in a no go determination. a history of substantial delivery delays will result in a no go determination

All awarded items must be delivered in full by October 16, 2026, with a one-time delivery window from October 1, 2026, through October 16, 2026. all awarded items must be delivered in full by october 16, 2026

Orders below $15,**** will be placed via government purchase card, and orders $15,**** and above will be placed via purchase order payment made via EFT. orders below 15, **** will be placed via government purchase card.

Awards will be based on past performance and price, with past performance being most important. awards will be based on past performance and price with past performance being most important.

Quoters must complete section 17a of standard form ****, including company name, phone number, point of contact, and unique entity id uei. quoters shall complete section 17a of standard form ****, including: company name, phone number, point of contact, and unique entity id uei.

Contractor failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractors history of past performance. contractor failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractors history of past performance.

Items that fail to meet specifications will be refused, and conditionally received items found unacceptable must be picked up at the vendors expense within one week. items that fail to meet specifications will be refused.

Weekly delivery dates for bread will begin October 5, 2026, through December 31, 2026.

Orders below 15,**** will be placed via government purchase card. Orders 15,**** and above will be placed via purchase order payment made via eft.

Awards will be based on past performance and price with past performance being most important.

Contractor failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractors history of past performance.

Past performance information maybe used by the government to make future award decisions and/or may result in a finding that the quoter is not responsible for the award of future requirements.

The anticipated date for receipt of quote is August 31, 2026, at 3:00 p. m. central standard time.

Price will be rated higher than past performance.

Each offeror is required per rfo far **** and c to complete their representations and certifications via www. ***. *. *

Failure to deliver within the established time frames will be considered as nonconformance under the contract terms and subject to termination.

Failure to deliver within the established time frames will be considered as nonconformance under the contract terms and subject to termination.