The Colville Tribes Fish and Wildlife Department is requesting bids for a fish wildlife riparian fence repair maintenance contract. Bids must be submitted by October 23, 2025. The work involves repairing and maintaining approximately **** miles of fencing. The contractor must conduct maintenance checks, repair damaged wires, and ensure the fence meets CTCR wildlife-friendly fencing specifications. A site visit is not required, but strongly encouraged. The Davis-Bacon Act applies. The project must be completed by December 31, 2026. The contractor must provide a work plan, schedule, and proof of insurance. Partial payments will be made periodically based on approved milestone completion or quarterly inspection cycles. Failure to meet the completion date or contract specifications may result in default.
The work must be completed by December 31, 2026, as stated in the bid notice.
Partial payments for completed and approved work at the agreed upon contract amount will be paid to the contractor periodically as agreed upon, as stated in the bid notice.
Award of contract shall be made to the responsive bidder and must provide all documentation listed, as stated in the bid notice.
To qualify for consideration all bid packets submitted must include the documents listed in the bid notice, such as the bid sheet, work plan, and proof of insurance.
Failure to meet the completion date or contract specifications may result in default, as stated in the bid notice.
A site visit is not required, however, prospective bidders are strongly encouraged to conduct at least one site visit or submit a waiver acknowledgment confirming they understand the conditions, as stated in the bid notice.
Contractors may submit a written appeal within 30 days of default determination for reconsideration by the contracting officer, as stated in the bid notice.