Attachment Government Bids & RFPs

The bid notice states Contract performance starts september 1, 2026.

The bid notice states payments will be made in accordance with the following partial payment schedule: monthly payments as per section i, sub section h, invoices, review and payment

The bid notice states The government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the government, price and other factors considered.

The bid notice states Offerors must be technically qualified and financially responsible to perform the work described in this solicitation.

The bid notice states he maximum ordered amount during the entire life of this contract is 3, 500, ****.

The project has a construction magnitude of between $500,000 and $1,000,000 and a POP of 120 calendar days.

Offerors are to identify self-performance iaw cfr title 13: business credit and assistance, chapter i, part 125government contracting programs **** contractor performance requirements limitations on subcontracting.

The construction magnitude is between $500,000 and $1,000,000.

The contractor shall begin performance within 10 calendar days and complete it within **** calendar days after receiving award, notice to proceed. The contractor shall begin performance within 10 calendar days and complete it within **** calendar days after receiving award, notice to proceed.

The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer. The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.

The award will be made with reasonable promptness to the responsible bidder submitting the lowest responsive bid in accordance with requirements and provisions herein. The award will be made with reasonable promptness to the responsible bidder submitting the lowest responsive bid in accordance with requirements and provisions herein.

All eligible contractors that are capable of successfully completing the work identified in the requirement can submit a bid. All eligible contractors that are capable of successfully completing the work identified in the requirement can submit a bid.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of contracting officer insert amount for each calendar day of delay until the work is completed or accepted. If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of contracting officer insert amount for each calendar day of delay until the work is completed or accepted.

No site visit will be coordinated for this requirement. o site visit will be coordinated for this requirement

All questions shall be in writing and submitted no later than 15 december 2025 10: 00 am. all questions shall be in writing and submitted no later than 15 december 2025 10: 00 am.

The magnitude of the requirement is between 5, 000, **** and 10, 000, ****. he magnitude of the requirement is between 5, 000, **** and 10, 000, ****.