Bonein Government Bids & RFPs

The items must be delivered by 1:00 pm on July 15, 2026, and goods are to be delivered from July 1st to 15th, 2026, Monday through Friday between 7:30 a. m. and 1:00 p. m. , excluding federal holidays.

Payment will be made by the code listed in block 17a. All orders over $15,**** will be placed on SF **** orders under $15,**** will be placed on a Government Purchase Card unless otherwise authorized by the Contracting Officer. All Government Purchase Card and SF **** transactions are fill or kill.

The evaluation factors are past performance and price. Past performance will be rated higher than price. The government will award to the responsible bidder's whose offer conforms to the solicitation and is considered to be the most advantageous to the government.

All potential bidders are advised that this solicitation includes the clause FAR **** for commercial items. Bidders should include their Data Universal Number System (DUNS) number in their offers. As of October ****, all vendors participating shall be registered in the SAM website www. ***. *. * contracting officer will verify registration in the SAM database prior to award by entering the potential awardee's DUNS number into the SAM database. As of January 1, ****, all potential bidders are required to complete the Annual Representations and Certifications Application (ORCA), which should be completed at http:orca. bpn. gov.

Failure to deliver within the established time frames will be considered as non conformance under the terms of the contract.

Failure to complete the registration procedures outlined in this clause may result in elimination from consideration for award. Failure to complete either of these registration procedures outlined in this solicitation, may result in elimination from consideration for award.

The delivery date for the products will be 30 days after receipt of order (ARO). Deliveries must be made between 7:00 AM and 2:00 PM CST, and federal holidays are excluded. Delivery schedules must be prearranged with the receiving warehouse.

The bid notice states that payment will be made by the Federal Bureau of Prisons, FCI Leavenworth office. Specific payment terms are detailed within the contract clauses, including provisions for prompt payment according to the Prompt Payment Act and regulations at 5 CFR part ****.

The bid notice includes FAR clause ****, which states that the contractor warrants and implies that the items delivered under this contract are merchantable and fit for use for the particular purpose described in this contract.

Awards will be made to the responsible quoters whose quote conforms to the requirements and is determined to provide the best value to the government, considering pricing per line item and past performance.

This acquisition is set aside for small business concerns. Offerors must be responsible and their quotes must conform to the requirements. Past performance will be evaluated on a go/no-go basis, assessing timeliness of deliveries and order accuracy.

The bid notice mentions that failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractor's history of past performance, which may impact future award decisions or a finding of responsibility.

The bid notice states that quotes must be good for 30 calendar days after the close of the solicitation. Information regarding protest after award is included in FAR clause ****.

The bid notice states that deliveries will be 30 days after receipt of order (ARO). Deliveries must be made between 7:00 am and 2:00 pm CST, and federal holidays will not be accepted. Delivery schedules must be prearranged with the receiving warehouse.

The bid notice indicates that payment will be made by the Federal Bureau of Prisons. Awards with a total value over the micro-purchase threshold of $15,000 will be awarded with a firm-fixed-price (FFP) purchase order. Awards with a total value under the micro-purchase threshold of $15,000 will be awarded with a firm-fixed-price (FFP) government purchase card transaction from the local food services department. Any subsequent award will require acceptance in the form of a signature by the contractor 48 hours after the signed purchase order has been delivered to the contractor.

The bid notice incorporates FAR ****, which includes a warranty clause. Specifically, paragraph 'o' states: The contractor warrants and implies that the items delivered under this contract are merchantable and fit for use for the particular purpose described in this contract.

The bid notice states that awards will be made to the responsible quoters whose quote conforms to the requirements and is determined to provide the best value to the government, considering the evaluation factors outlined: 1. Price, and 2. Past Performance (Go/No-Go evaluation based on timeliness of deliveries and order accuracy/completeness).

The bid notice states that this acquisition is set aside for small business concerns. The NAICS code for this requirement is **** with a small business size standard of 700 employees. Offerors must be responsible quoters whose quote conforms to the requirements.

The bid notice mentions that failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractor's history of past performance. Past performance information may be used by the government to make future award decisions and/or may result in a finding that the quoter is not responsible for the award of future requirements.

The bid notice states that quotes must be good for 30 calendar days after the close of the solicitation.

The bid notice states that deliveries will begin July 1, 2026, and will not be accepted prior to that date.

The bid notice states that payments will be processed via electronic funds transfer EFT or via government purchase card for awards of $15,**** or less.

The bid notice states that evaluation factors include price and past performance.

The bid notice states that all offerors must have an active registration and completed representations and certifications within the System for Award Management (SAM). Offerors must also include a letter of halal certification with their bid for consideration.

The bid notice states that failure to comply with the religious diet specifications will result in your quoted item not being considered for award.

The bid notice states delivery will not be accepted no sooner than april 1st, 2026.

The bid notice states orders over 15, ****, payments will be made using electronic funds transfer eft or via government purchase card for awards of 15, **** or less.

The bid notice states he government will award to the responsible offer s whose offer, conforming to the solicitation that are considered to be most advantageous to the government.

The bid notice states must include a letter of kosher certification with your quote.