Touch Panel Government Bids & RFPs

The bid notice states that the estimated delivery date must be included in the response.

The bid notice states that items must be covered under the manufacturers warranty.

The bid notice states that he award will be made on the basis of lowest evaluated price of proposals meeting or exceeding the acceptability standards.

The bid notice states that vendors must be teguar corporation authorized distributors resellers and provide documentation to be considered.

The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed. The contractor shall begin performance within 15 calendar days and complete it within 365 calendar days after receiving award, notice to proceed.

The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer. The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.

Award will be made to the responsible offerors whose offer conforms to the solicitation and represents the best value to the government, price and nonprice factors considered. Award will be made to the responsible offerors whose offer conforms to the solicitation and represents the best value to the government, price and nonprice factors considered.

The government intends to evaluate proposals and award a contract without discussions with offerors except clarifications as described in ****. The government intends to evaluate proposals and award a contract without discussions with offerors except clarifications as described in ****.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of see note for each calendar day of delay until the work is completed or accepted. if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of see note for each calendar day of delay until the work is completed or accepted.

Site visit details for the seed project will be determined via amendment. Site visit details for the seed project will be determined via amendment.

The magnitude of construction for the seed project is between 10,000,000 and 25,000,000. in accordance with dfars ****, the magnitude of construction for the seed project is between 10, 000, 000 and 25, 000, 000.