Concrete Sealer Government Bids & RFPs

Delivery must be made between 8:00 AM and 5:00 PM Monday through Thursday, except on regularly observed state or federal holidays.

Payment will be made within thirty (30) days from receipt of a correct invoice, subject to the availability of funds.

Manufacturer's standard warranty must apply unless otherwise stated in this solicitation.

Awards will be based on the lowest price and respondents ability to meet the requirements as specified in the solicitation.

Default in promised delivery or service date authorizes txdot to purchase goods or services elsewhere and charge the full increase, if any, in cost and handling to defaulting vendor.

A respondent may request a debriefing meeting within 30 calendar days of the award being posted.

Contacting any other txdot personnel regarding this solicitation may result in the respondent being disqualified.

All work shall be completed within 180 calendar days from the time of notice to proceed to substantial completion. All work shall be completed within 180 calendar days from the time of notice to proceed.

As work under the contract is performed, the contractor may submit a partial payment request for review. After approval, a partial payment shall be made representing the work completed less retainage. As work under the contract is performed, the contractor may submit a partial payment request to the City of Peekskill Department of Planning and Development for review.

The contractor shall guarantee all materials and workmanship for one year in accordance with the specifications. The contractor shall guarantee all materials and workmanship for one 1 year in accordance with all conditions set forth in these specifications.

The contract will be awarded to the lowest responsible eligible bidder. The contract will, at the discretion of the City of Peekskill, be awarded on the basis of competitive bids to the lowest responsible eligible bidder. . .

The city may investigate bidder qualifications and reserves the right to reject any bid if the bidder is not properly qualified. The city may make such investigations as it deems necessary to determine the qualifications of the bidder to perform the work. . .

The contractor agrees to pay **** as liquidated damages for each consecutive calendar day the work is not completed after the 180-day period. The contractor agrees to pay as liquidated damages the sum of five hundred dollars ****, for each consecutive calendar day thereafter.

A site visit will follow the pre-bid meeting. The meeting and visit specifics will be posted on the city's bidrfp webpage. A site visit will follow the prebid meeting.

Fraudulent statements shall cause rejection of the proposal and forfeiture of bid security. Failure to meet qualification requirements may also lead to rejection. Fraudulent statements shall cause rejection of proposal and forfeiture of the related bid security.

All work shall be completed within 180 calendar days from the time of notice to proceed to substantial completion. All work shall be completed within 180 calendar days from the time of notice to proceed.

As work under the contract is performed, the contractor may submit a partial payment request for review. After approval, a partial payment shall be made representing the work completed less retainage. As work under the contract is performed, the contractor may submit a partial payment request to the City of Peekskill Department of Planning and Development for review.

The contractor shall guarantee all materials and workmanship for one year in accordance with all conditions set forth in the specifications. The contractor shall guarantee all materials and workmanship for one 1 year in accordance with all conditions set forth in these specifications.

The contract will be awarded to the lowest responsible eligible bidder. The contract will, at the discretion of the City of Peekskill, be awarded on the basis of competitive bids to the lowest responsible eligible bidder based on the following criteria:

The city may investigate bidder qualifications and reserves the right to reject any bid if the bidder is not properly qualified. The city may make such investigations as it deems necessary to determine the qualifications of the bidder to perform the work, and the bidder shall furnish information and data for this purpose as may be required.

The contractor agrees to pay **** as liquidated damages for each consecutive calendar day the work is not completed after the 180-day period. The contractor agrees to pay as liquidated damages the sum of five hundred dollars ****, for each consecutive calendar day thereafter.

A site visit will follow the pre-bid meeting. A site visit will follow the prebid meeting.

Fraudulent statements shall cause rejection of the proposal and forfeiture of the related bid security. Fraudulent statements shall cause rejection of proposal and forfeiture of the related bid security.

Submittals must include manufacturers' qualifications and product data for all finishing products and special coatings, including VOC content.

Submit two paper chip samples, 12 x 12 inch in size illustrating range of colors and textures available for each surface finishing product scheduled.

Substantial completion shall be achieved within seventy 70 calendar days following issuance of the full notice to proceed. Final completion shall be achieved within twenty-eight 28 calendar days after substantial completion.

The contract will be awarded to the responsible bidder submitting the lowest proposal complying with these contract documents provided the bid is reasonable and in the best interest of the city of Kirkland.

The bidder shall have successfully completed at least one construction, renovation, or systems installation project within an active and occupied municipal facility, with a construction value of $100,000 or greater, within the past five 5 years.

Bidder must agree to pay as liquidated damages the sum of **** for each consecutive calendar day that substantial completion is delayed and the sum of **** thereafter for each consecutive calendar day that final completion is delayed.

Attendance at the pre-bid conference meeting on site is mandatory.

Questions regarding this project must be submitted in writing no later than July 17, 2026, at 5pm.

Any one or more of the following causes may be considered sufficient for the disqualification of a bidder and the rejection of its bid or bids: evidence of collusion among bidders, lack of expertise, uncompleted work under other contracts, being in arrears on existing contracts, or defaulting on a previous contract.

The estimated bid amount is approximately $175,000 excluding sales tax.