The Calcasieu Parish Sheriffs Office (CPSO) seeks proposals to upgrade the avionics on a Cessna T206H aircraft. The scope includes upgrading the Garmin **** to **** NXi, installing autopilot, SVS, SAR, and a new display. Installation must be completed within 31 calendar days, with delivery required before January 15, 2027. Proposals must be submitted in four paper copies by September 9, 2026, at 10:00 am CST. Award will be based on the best overall proposal, not solely the lowest cost. A one-year installation warranty is guaranteed.
Installation must be completed within 31 calendar days, and delivery must occur prior to January 15, 2027. Installation must be completed within 31 calendar days.
Payment in full is due upon successful completion of the acceptance flight and CPSO's written acceptance of the aircraft. Payment in full is due upon successful completion of the acceptance flight and cpsos written acceptance of the aircraft.
The awarded proposer agrees to a one-year installation warranty, which begins on the date the aircraft is delivered back to the CPSO. awarded proposer agrees to a oneyear installation warranty.
The contract will be awarded to the respondent who offers the best combination of attributes based upon the evaluation criteria. the cpso will award the contract resulting from this rfp not necessarily to the respondent offering the least expensive cost proposal but to the respondent who offers the best combination of attributes based upon the evaluation criteria.
Proposers must be a Garmin authorized dealer and hold an appropriate FAA Part 145 repair station certificate and rating. Proposer must be a garmin authorized dealer and Proposer must hold an appropriate faa part 145 repair station certificate and rating for the work described
A penalty of 1% of the RFP award price will be assessed for each calendar day of delayed delivery beyond the 31-day period, unless excusable delay applies. a penalty of 1 of the rfp award price will be assessed for each calendar day of delayed delivery beyond the 31day period
Written questions must be submitted by Tuesday, August 25, 2026, at 10:00 am CST. written questions deadline. . . . . . . . tuesday, august 25, 2026 @10: 00am cst
Failure to submit four paper copies by the deadline will be considered a no bid, even if an online submission was made. failure to submit the paper copies by the deadline will be considered a no bid even if a submission was made online at bidnetdirect. com.
™
