Heating Pad Government Bids & RFPs

The state will incur no penalty for late payment if payment is made in 30 or fewer days from receipt of goods or services and an uncontested invoice. the state will incur no penalty for late payment if payment is made in 30 or fewer days from receipt of goods or services and an uncontested invoice.

Manufacturers standard warranty shall apply unless otherwise stated in the ifb. manufacturers standard warranty shall apply unless otherwise stated in the ifb.

The state reserves the right to make an award on the basis of best value or in any other combination that will serve the best interests of the state. the state reserves the right to make an award on the basis of best value or in any other combination that will serve the best interests of the state

In the event a successful respondent fails to perform services or complete the obligations under the contract in a timely manner, tjjd may require successful respondent to pay, as liquidated damages and not as a penalty, an amount equivalent to 2 of the total cost for services or obligations not completed as required by the contract per calendar day of delay. in the event a successful respondent fails to perform services or complete the obligations under the contract in a timely manner, tjjd may require successful respondent to pay, as liquidated damages and not as a penalty, an amount equivalent to 2 of the total cost for services or obligations not completed as required by the contract per calendar day of delay.

Contractors are highly recommended to do a site visit before placing bid. contractors are highly recommended to do a site visit before placing bid.

Samples, when requested, must be furnished free of expense to tjjd. samples, when requested, must be furnished free of expense to tjjd.

Late andor unsigned bids will not be considered under any circumstances. late andor unsigned bids will not be considered under any circumstances.