Work Environment Government Bids & RFPs

The period of performance for this contract shall be for 180 days.

The government will award a firm fixed price contract.

All personnel performing asbestos abatement activities shall be adequately trained and shall have their current state certification at the abatement site.

Continued lack of compliance with specification requirements by the contractor may be cause for default, as determined by the contracting officer.

Any prebid site visits held before the contract award will be conducted under strict security controls.

The bid notice states that quotations shall be received by email by 10:00 AM EST, May 12, 2026. Quotations shall be received by email to miranda amir at ***@***. *. * and by 10: 00 am est, may 12, 2026.

The bid notice states that the basis for award selection is lowest price technically acceptable (LPTA). The basis for award selection is lowest price technically acceptable lpta.

The bid notice states that to be considered for award, offerors must have an active SAM. gov registration. To be considered for award, offeror must have an active sam. gov registration.

The bid notice states that there is a mandatory site visit on Monday, April 27, 2026, at 10:30 AM EST. Mandatory site visit: monday, april 27, 2026, at 10: 30am est.

The official solicitation and all associated attachments are expected to be posted on or about May 21, 2026.

The government intends to utilize a hybrid Highest Technically Rated Offeror (HTRO), with a Minimum Technical Threshold Rating (MTTR) source selection methodology for this acquisition.

All parties interested in doing business with the government must be registered in the System for Award Management (SAM) database to be eligible for award.

The total ceiling for this IDIQ contract vehicle is $3. 5 billion.

The contractor shall begin performance within 5 calendar days and complete it within 54 calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. The contractor is to complete the entire basic work ready for use, not later than fiftyfour 54 calendar days after the date the contractor receives the notice to proceed. Bidders are reminded that dredging work is prohibited from sheets six 6 to ten 10 during the timeframe 01 October 2026 to 30 November 2026. The delivery schedule indicates delivery on or before 30 Nov 2026 for all items.

The bid notice indicates that payment will be made by the contracting officer. Specific payment terms are detailed within the FAR clauses incorporated by reference, such as FAR ****, Payments under Fixed-Price Construction Contracts, and FAR ****, Progress Payments.

Award of contract will be based on the responsible and responsive bidder with the lowest total price for the total of the CLINS **** through ****.

The solicitation is unrestricted and open to full and open competition with a HUBZone price evaluation preference. Bidders must be responsible and responsive.

Liquidated damages of $2,**** per calendar day of delay will be assessed to the contractor until all work under the contract is accepted as complete.

The bid notice does not explicitly state a deadline for challenging the bid. However, FAR ****, Service of Protest, and FAR ****, Protest After Award, outline procedures and timelines for protests.

The project magnitude range is between $5,000,**** and $15,000,****.

The bid notice states that the work must be conducted in July-August of 2026. his work must be conducted in july august of 2026.

The bid notice states that the system for award management SAM registration for interested contractors must show that they are an active small business to be considered for inclusion in the future solicitation. he system for award management sam registration for interested contractors must show that they are an active small business to be considered for inclusion in the future solicitation.