Wild Government Bids & RFPs

To protest this sole source determination, a protestor must provide a detailed description of how the protestor could providedevices with the mandatory specifications listed above.

Protests must be submitted by july 31, 2026 at 2: 00 pm pt.

Delivery may be a factor in determining best value award. Vendor must contact TPWD point of contact to schedule delivery date and time, providing one week notice. Delivery in calendar days after receipt of order.

Payment normally will be made to the contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of goods/services ordered, whichever is later.

The unit shall be warranted against defects in material and workmanship for the manufacturer's standard warranty for government use. The warranty begins on the date the unit is determined to meet specifications and accepted by TPWD.

TPWD will award a contract to the respondent whose quote is considered to be the best value to TPWD, price and other factors considered. Factors may include lowest price, ability/qualifications, delivery schedule, and past performance.

TPWD will only award a contract to an actively licensed marine dealer, manufacturer, or manufacturer's authorized distributor. Documentation is required if a respondent is a manufacturer's authorized distributor.

Default in promised delivery days after receipt of order without accepted reasons or failure to meet specifications authorizes TPWD to purchase goods and services elsewhere and charge any increased costs to the contractor.

A pre-delivery inspection of assembled boats with accessories, outboard motor, and boat trailer is mandatory prior to scheduling delivery. The inspection will be performed at the vendor's facility.

Failure to sign the bid, failure to take exception to specifications or provide reference data, or prohibited communications may result in bid disqualification.

Bids are due by 2:00 PM CT on August 07, 2026. Delivery terms are to be specified with the bid response, and delivery may be a factor in determining the best value award.

Payment normally will be made to the contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of goods/services ordered, whichever is later.

The unit shall be warranted against defects in material and workmanship for the manufacturer's standard warranty for government use. The warranty begins on the date the unit is determined to meet specifications and accepted by TPWD.

TPWD will award a contract to the respondent whose quote is considered to be the best value to TPWD, price and other factors considered. Factors may include lowest price, ability/qualifications/experience, delivery service schedule, and past performance.

TPWD will only award a contract to an actively licensed marine dealer, manufacturer, or manufacturer's authorized distributor. If a respondent is a manufacturer's authorized distributor, documentation is required with the bid submission.

Default in promised delivery days after receipt of order without accepted reasons or failure to meet specifications authorizes TPWD to purchase goods and services elsewhere and charge any increased costs to the contractor.

A pre-delivery inspection of assembled boats with accessories, outboard motor, and boat trailer is mandatory prior to scheduling delivery. This inspection will be performed at the vendor's facility.

Failure to sign the bid, failure to take exception to specifications or provide reference data, or providing incomplete information may result in bid disqualification.

Delivery may be a factor in determining best value award. Vendor must contact TPWD point of contact to schedule delivery date and time, providing one week notice. Delivery may be a factor in determining best value award.

Payment normally will be made to the contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of goods/services ordered, whichever is later. Payment normally will be made to the contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of goodsservices ordered, whichever is later.

The unit shall be warranted against defects in material and workmanship for the manufacturer's standard warranty for government use. The unit shall be warranted against defects in material and workmanship for the manufacturers standard warranty for government use.

TPWD will award a contract to the respondent whose quote is considered to be the best value to TPWD, price and other factors considered. TPWD will award a contracts to the respondents whose quote is considered to be the best value to tpwd, price and other factors considered.

TPWD will only award a contract to an actively licensed marine dealer, manufacturer or manufacturer's authorized distributor. TPWD will only award a contract to an actively licensed marine dealer, manufacturer or manufacturers authorized distributor of makemodel boat on which bid is placed.

Default in promised delivery days after receipt of order without accepted reasons or failure to meet specifications authorizes TPWD to purchase goods and services elsewhere and charge any increased costs to the contractor. Default in promised delivery days after receipt of order without accepted reasons or failure to meet specifications authorizes tpwd to purchase goods and services of this contract elsewhere and charge any increased costs for the goods and services, including the cost of resoliciting, to the contractor.

A pre-delivery inspection of the assembled boat with accessories, outboard motor, and boat trailer is mandatory prior to scheduling delivery. Vendor shall contact TPWD boating law administrator and assistant boating law administrator to schedule an inspection of assembled boats with accessories, outboard motor, and boat trailer prior to scheduling delivery to location as specified in section 7. 3.

Failure to sign the bid, failure to take exception to specifications or provide reference data, or prohibited communications may result in bid disqualification. Failure to sign the bid above will disqualify bid.

The period of performance is 60 calendar days or less after receipt of award. delivery date period of performance: 60 or less days after receipt of award fob destination.

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform (IPP). payment requests must be submitted electronically through the u. s. department of the treasurysinvoice processing platform system ipp.

The equipment includes the standard manufacturer's warranty. standard manufacturers warrantyoperators manual and any accompanying standard issue manuals, i. e. service manual, partsmanualcurrent model year 2026

Award will be made to the responsible small business offeror whose quotation is the lowest price technically acceptable (LPTA). award shall be made to the responsible small business offeror whose quotation, in conforming to this rfq, provides the lowest price technically acceptable lpta offer to the government.

This is a small business set-aside. Offerors must be responsible small business concerns. this is a small business set aside. a. 10 calendar days b. 20 calendar days c. 30 calendar days d. calendar days12. discount for prompt payment number percentagenote: additional provisions and representations are are not attached. 13. name and address of quoter 14. signature of person authorized to 15. date of quotation sign quotationa. name of quoterb. street addressc. county area coded. city e. state f. zip code c. title type or print numberauthorized for local reproduction standard form 18 **** edition not usable prescribed by gsafar 48 cfr **** section 1 pricing1. 1 generalthis acquisition is being conducted in accordance with far part 12 acquisition of commercialproducts and commercial services as specified in the federal acquisition regulation faroverhaul. the united states department of the interior, on behalf of the national park service nps, anticipates awarding a firmfixedprice ffp purchase order for a brush wood chipper. theapplicable naics code is 333120. the applicable psc code is 9130. this is a small business setaside.

If the contractor fails to respond in a timely manner to any requirements of the purchase order, delay will be attributed to the contractor and the price may be subject to a downward adjustment. if the contractor fails to respond in a timely manner to any requirements of the purchase order, delay will be attributed to the contractor and the price may be subject to a downward adjustment.

Failure to submit any required information may result in rejection of the quotation without further discussion. failure to submit any required information may result in rejection of the quotation without further discussion.