Reflective Tape Government Bids & RFPs

Vendors shall deliver within five (5) days after an order is placed, unless otherwise noted. vendors shall deliver within five 5 days after an order is placed

Invoices must include company name, invoice number, order number, quantities, descriptions, prices, total amount, and bid number. invoices shall not include any fees, warranties, or charges other than the prices or labor rates quoted

Bids will be awarded to the lowest responsible bidder. bids will be awarded to the lowest responsible bidder

Bidders must submit a notarized bid, business license, E-Verify enrollment, and affidavits. the following forms must be submitted with the bid package: 1. invitation to bid response form . . . 2. business license . . . 7. everify memorandum of understanding

Bids may be rejected for failure to utilize bid forms, lack of signature, incomplete bids, or evidence of collusion. bids may also be rejected for any of but not limited to the following causes: a. failure to utilize bid forms provided by madison county

Barricading materials must be dropped off at specified locations in City Row greenspace before end of day on Thursday, November 19, 2026. will need to be dropped off at specified locations in city row greenspace before the end of the day on thursday, november 19, 2026

Payment will be made in one sum at completion of contract, with optional partial payments of 90% at monthly intervals if bonds are furnished. payment for the work will be made in one sum at the completion of the contract except that, at the citys option, partial payments aggregating 90 of the value of the completed work may be made at monthly intervals

Contractor must provide a written guarantee to remedy defects due to faulty materials or workmanship within one year from final acceptance. guarantee to remedy any defects due to faulty materials or workmanship which appear in the work within one year from the date of final acceptance

Vendors must not be debarred, suspended, or ineligible; must be current on taxes and fees due to the city. all vendors shall be current in payment of any taxes, licenses, fees, permits or any other monies due the city of lansing

Bids may be rejected if not returned on the official form, and bids cannot be withdrawn within 90 days after opening without forfeiting bid security. bids may not be withdrawn within 90 days after opening date without forfeiting bid security

Delivery shall be made within thirty (30) days from the date of notification of award. delivery shall be made within thirty 30 days from the date of notification of award.

Payments are made after submission of invoices and required documentation to the Town's Department of Finance. payments are to be made after submission of invoices andor such other documentation as is required by the towns department of finance.

Proposals must be regular, with unauthorized conditions cause for rejection. all proposals must be regular in every respect. unauthorized conditions, limitations, or provisions shall be cause for rejection.

The town might require samples prior to approval and purchase. the town might require samples prior to approval and purchase.

Proposals received after the deadline will be returned. submissions received after this time will be returned to the sender.

Payment will be made within thirty 30 days after satisfactory acceptance by the county of all completed services and receipt of a valid invoice, in accordance with the texas governmentcode, chapter **** will be made within thirty 30 days after satisfactory acceptance by thecounty of all completed services and receipt of a valid invoice

Criteria utilized by guadalupe county for determining the lowest responsible bidder includes, but is not limited to, bidder meeting the countys published specifications, biddersexperience, skill, ability, business judgment, financial capacity, possession of the necessary facilities orequipment, previous performance, reputation, promptness, and any factor which could reasonably beasserted as being relevant to successful performance. criteria utilized by guadalupe county for determining the lowest responsible bidder includes, but is not limited to, bidder meeting the countys published specifications, biddersexperience, skill, ability, business judgment, financial capacity, possession of the necessary facilities orequipment, previous performance, reputation, promptness, and any factor which could reasonably beasserted as being relevant to successful performance.

To be considered for this purchase, your firm must meet the qualifications and satisfy the requirements set forth in the ifb. to be considered for this purchase, your firm must meet the qualifications and satisfy the requirements set forth in the ifb.

Liquidated damages for delay in completion are five hundred dollars **** per calendar day. liquidated damages of five hundred dollars **** per calendar day in the event of its failure to complete work inaccordance with the schedule set forth in the agreement.

Any sample with percent air voids of more than 10 or less than 2 will be rejected. any sample with percent air voids of more than 10 or less than 2 will be rejected.

Protests before award must be submitted in writing to the purchasing agent not later than six 6 calendar days after bid opening. protests before award must be submitted in writing to the purchasing agent notlater than six 6 calendar days after bid opening,

Incomplete bid submissions all requested required documents signatures will be considered nonresponsive and will be rejected. incomplete bid submissions all requestedrequireddocumentssignatures will be considered nonresponsive and will be rejected.

The contract period is for one year effective the date commissioners courtawards the contract. the contract period is for one year effective the date commissioners courtawards the contract.