The contractor must provide personnel, materials, and equipment for swimming pool rehabilitation work at the U. S. Consulate General compound in Jeddah, Saudi Arabia. The contract is a firm fixed price. Scope includes grout repair, tile replacement, ladder inspection, and coping repair. The contractor must submit a Quality Control Plan (QCP) within 7 calendar days after award. The project duration is 30 calendar days from the Notice to Proceed (NTP). Daily quality control reports (QCR) are required. Safety plans and hazard analyses must be submitted after the site survey.
The contractor shall complete the entire work ready for use not later than 30 calendar days. complete the entire work ready for use not later than 30 calendar days.
Payment requests, made no more frequently than monthly, shall cover the value of labor and materials completed and in place. The contractors requests for payment, which shall be made no more frequently than monthly shallcover the value of labor and materials completed and in place
Special warranties shall be subject to the terms of FAR ****, Warranty of Construction, unless they conflict. any special warranties that may be required under the contract shall be subject to the terms of far****, warranty of construction, unless they conflict with the terms of such special warranties.
The technical evaluation will be based on company profile, demonstrated experience in similar projects, proposed Gantt chart, resumes of key personnel, and complete submittals. The technical evaluation will be based on the following factors: 1. the company profile and prequalification documents demonstrate the contractors capability to execute the project to a high standard.
The offeror must provide details of projects completed within the last five years and provide resumes of key project management personnel. The offeror must provide details of projects completed within the last five years.
If the contractor fails to complete the work within the specified time, they shall pay liquidated damages of 100 for each calendar day of delay. if the contractor fails to complete the work within the time specified in the contract, or any extension, the contractor shall pay liquidated damages to the government in the amount of 100 for eachcalendar day of delay until the work is completed or accepted.
Samples must be provided for approval at the contractor's expense when directed by the contracting officer or COR. The contractor shall provide this information in a timely manner to permit the government to evaluate theinformation against the requirements of the contract. The contractor shall provide a submittal register ten 10days after contract award showing when shop drawings, samples, or submittals shall be made.
Failure to timely submit evidence of insurance may result in rescinding or termination of the contract by the government. failure to timely submit this evidence, in a form acceptable to the contracting officer, may result in rescindingor termination of the contract by the government.
