Road Safety Government Bids & RFPs

The project completion deadline is November 15, 2026. failure to complete on time shall result in liquidated damages in the amount indicated in the current indot schedule, not including weekends, as liquidated damages from any money due the contractor.

Final payment will be based on actual quantities installed. final payment will be based on actual quantities installed as provided in the contract documents.

Contractors must complete and submit a notarized Comprehensive Compliance Form (CCF) and Contractor's Bid for Public Work Form 96. all contractors, subcontractors, and bidders for contracts with the city of columbus shall be required to complete and submit a notarized comprehensive compliance form ccf. . .

Liquidated damages will apply for failure to complete the project on time. failure to complete on time shall result in liquidated damages in the amount indicated in the current indot schedule, not including weekends, as liquidated damages from any money due the contractor.

Failure to submit the CCF will constitute a material defect in the bid. failure to submit the ccf will constitute a material defect in the bid.

Contractor warrants that all materials and equipment will be new unless otherwise specified and that all work will be of good quality and free from faults or defects. The contractor shall rebuild, repair, restore, and make good, without extra compensation, all injuries or damages to any portion of the work occasioned by any cause before its completion and acceptance. The contractor warrants and guarantees to the parish that all materials and equipment will be new unless otherwise specified and that all work will be of good quality and free from faults or defects and in accordance with the requirements of the contract documents.

Respondents must visit the site and thoroughly examine drawings, specifications, and contract documents. The contractor shall provide competent, suitably qualified personnel to survey and lay out the work and perform construction. each respondent shall visit the site of the proposed work and fully acquaint itself with all surface and subsurface conditions as they may exist so that it may fully understand this quote request.

Each respondent shall visit the site of the proposed work and fully acquaint itself with all surface and subsurface conditions. each respondent shall visit the site of the proposed work and fully acquaint itself with all surface and subsurface conditions as they may exist so that it may fully understand this quote request.

Samples of materials furnished under the contract shall be submitted for approval to the parish when and as directed. Samples of materials furnished under the contract shall be submitted for approval to the parish when and as directed.

Failure of the contractor to keep the necessary qualified personnel on the work shall be considered cause for termination of the contract by the parish. Failure of the contractor to keep the necessary qualified personnel on the work shall be considered cause for termination of the contract by the parish.

$10,000,**** turning radii improvements - 10 million 3, 000

Bids are due by July 30, 2026, at 2:00 PM EDT. Bids will be received by lumpkin county board of commissioners, purchasing department, 99 courthouse hill, suite d, dahlonega, georgia **** until 2:00 pm, edt on july 30, 2026.

Approved invoices will be paid within 30 days of approval, less retainage if applicable. Approved invoices less retainage, if applicable will be paid within 30 days of approval.

The contract will be awarded to the lowest responsive and responsible bidder. any purchase order contract awarded pursuant to this invitation to bid shall be awarded to the lowest responsive and responsible bidder whose bid response meets the requirements and specifications set forth in this invitation to bid.

A responsible bidder is one who has the capacity to fully perform the contract requirements and the integrity and reliability for good faith performance. a responsible bidder is a bidder who has the capacity in all respects to perform fully the contract requirements and the integrity and reliability which will assure good faith performance.

Liquidated damages will be charged at a rate of **** per day if the project is not completed by the completion date. Liquidation damages on this project will be charged at a rate of **** per day if not completed by the completion date.

A mandatory pre-bid meeting will be held on July 16, 2026, at 2:00 PM. A mandatory prebid meeting will be held july 16, 2026 at 2:00 pm.

Bidders shall have up to 48 hours after bid opening to notify the county in writing of an obvious clerical error to withdraw a bid. bidders shall have up to fortyeight 48 hours to notify the lumpkin county purchasing department, in writing, of an obvious clerical error made in the calculation of bid in order to withdraw a bid after bid opening.

Contractors are not allowed to communicate with county staff or elected officials except through the purchasing agent, at the pre-bid meeting, or as provided by existing work agreements. Violation may lead to rejection of the submittal. contractors are not allowed to communicate for any reason with any county staff or elected officials except: 1 through the purchasing agent named herein, 2 at the prebid meeting, if applicable or 3 as provided by existing work agreements.