Dairy Government Bids & RFPs

Deliveries must be made within 30 days after receipt of order. delivery of all products within 30 days after receipt of order

The award will be made to the responsible quoters providing the best value to the government based on the following factors: price: evaluated for fairness and reasonableness. past performance: evaluation includes prior experience and similar performance history. the contracting officer co will consider late deliveries, missing items, and frequent substitutions. delivery: a documented history of on time deliveries and reliability will be considered.

Quoters must include their unique entity identifier uei. all vendors must be active in sam. gov at the time of quote, award, and through final payment.

Failure to deliver within the established time frame will be considered as nonconformance to the terms of the contract. failure to deliver within the established time frame will be considered as nonconformance to the terms of the contract.

Contractor failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractors history of past performance. contractor failure to meet delivery schedules without an excusable delay and/or failure to conform to contract specifications will negatively affect the contractors history of past performance.

Delivery is required on or before **** unless special instructions are stated in the specifications. delivery to fci otisville by **** unless special instructions stated in the specifications

Awards will be made to the responsible quoters whose quote conforms to the requirements and is determined to provide the best value to the government, considering the evaluation factors outlined below. awards will be made to the responsible quoter s whose quote conforms to the requirements and is determined to provide the best value to the government

The government will evaluate the quoters past performance on a go no go basis, based on timeliness of deliveries and order accuracy and completeness. the government will evaluate the quoters past performance on a go no go basis

Failure to deliver by the requested deadline shall result in a cancelation of the order unless negotiated with the co cor. failure to deliver by the requested deadline shall result in a cancelation of the order unless negotiated with the co cor.

A history of substantial delivery delays or a pattern of incomplete or inaccurate deliveries will result in a no go determination. a history of substantial delivery delays will result in a no go determination

Deliveries will be expected on a weekly basis with orders deliveries anticipated twice a week on monday and wednesday. deliveries will be expected on a weekly basis with orders deliveries anticipated twice a week on monday and wednesday.

Awards will be made to the responsible quoter s whose quote conforms to the requirements and is determined to provide the best value to the government, considering the evaluation factors outlined below. awards will be made to the responsible quoter s whose quote conforms to the requirements and is determined to provide the best value to the government

The government will evaluate the quoters past performance on a go no go basis. the government will evaluate the quoters past performance on a go no go basis.

A history of substantial delivery delays will result in a no go determination. a history of substantial delivery delays will result in a no go determination.

Delivery is required to FCI Otisville by **** unless special instructions stated in the specifications. delivery to fci otisville by **** unless special instructions stated in the specifications

Awards will be made to the responsible quoters whose quote conforms to the requirements and is determined to provide the best value to the government, considering the evaluation factors outlined below. the government will evaluate the quoters proposed price to ensure it is fair and reasonable

Vendor must present crc certification at time of offer to be considered for crc requirements. prepared meals must meet crc standardsvendor must present crc certification at time of offer to be considered for crc requirements.

A history of substantial delivery delays will result in a no go determination. a history of substantial delivery delays will result in a no go determination.

Delivery is to be completed within thirty 30 days of placed order. delivery is to be completed within thirty 30 days of placed order.

Payment by electronic funds transfer is **** payment by electronic funds transfersystem for award management oct 2018

Awards will be made to the responsible quoters whose quote conforms to the requirements and is determined to provide the best value to the government, considering the evaluation factors outlined below. awards will be made to the responsible quoters whose quote conforms to the requirements and is determined to provide the best value to the government

Offerors must be registered in the SAM database if doing business with the federal government after September 30, ****. this solicitation includes the clause at far ****, for commercial items, system for award management sam. this clause requires all contractors doing business with thefederal government after september 30, ****, to be registered in the sam database.

Items not delivered within the required time frame may be subject to cancelation and any all shipping and restocking fees will be the responsibility of the vendor. items not delivered within the required time frame may be subject to cancelation and anyallshipping and restocking fees will be the responsibility of the vendor.

A history of substantial delivery delays will result in a no go determination. a history of substantial delivery delays will result in a nogodetermination.

Delivery on or before: **** on or before: ****