The solicitation is for the Gas Alley Modernization Project at Fort Drum, NY. The project includes construction of a new two-lane road, demolition and reconstruction of existing roadways, and related work. The government estimates the project can be completed within 12 months from the notice to proceed. Bids are due by 2:00 PM EST on March 3, 2026. The project is a 100% small business set-aside. The government will make progress payments to the contractor when requested as work progresses, but not more frequently than monthly, in amounts of 2,500 or more approved by the contracting officer. The contractor shall complete the entire work ready for use not later than 365 calendar days from notice to proceed. Site visits may be arranged during normal duty hours by contacting the person listed in the solicitation. The basis of evaluation will be the lowest responsive, responsible bid based on the total amount for the base bid items plus all the optional bid items.
The contractor shall complete the entire work ready for use not later than 365 calendar days from notice to proceed. he contractor shall be required to a commence work under this contract within 5calendar days calendar days after the date the contractor receives the notice to proceed, b prosecute the work diligently, and c complete the entire work ready for use not later than 365 calendar days from notice to proceed.
The government will make progress payments to the contractor when requested as work progresses, but not more frequently than monthly, in amounts of 2,500 or more approved by the contracting officer, under the following conditions: he government will make progress payments to the contractor when requested as work progresses, but not more frequently than monthly, in amounts of 2, 500 or more approved by the contracting officer, under the following conditions:
The basis of evaluation will be the lowest responsive, responsible bid based on the total amount for the base bid items plus all the optional bid items. he basis of evaluation will be the lowest responsive, responsible bid based on the total amount for the base bid items plus all the optional bid items. line items **** thru ****.
This is a 100 small business setaside. 1. this is a 100 small business setaside.
If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government. if the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of first tier total costday 2, **** for each calendar day of delay until the work is completed or accepted. second tier total costday **** for each calendar day of delay until the work is completed or accepted.
Site visits may be arranged during normal duty hours by contacting: name: site visit will be announced through future amendment. b site visits may be arranged during normal duty hours by contacting: name: site visit will be announced through future amendment.
The anticipated magnitude of construction is between 5,000,00 and 10,000,000. he anticipated magnitude of construction is between 5, 000, 00 and 10, 000, 000.
