Bilge Pump Government Bids & RFPs

The contractor will be expected to complete the removal within 180 calendar days after receiving the notice to proceed. Contractor shall commence operations no later than 45 calendar days after receipt of the NTP. The bid notice states The deadline for submission of solicitation responses June 3, 2026, at 2:00 p. m. CT.

The bid notice states All project deliverables must be accepted by the designated GLO representative prior to approval of contractors requests for payment. The contractor may only request payment or submit invoices after all work has been completed and reviewed and approved by the GLO.

The bid notice states The GLO shall not be obligated to accept the lowest priced proposal but will award a contract to the respondents that provides the best value to the state of Texas for each individual region.

The bid notice states Respondent must have recently been in business performing similar work as detailed in Article II for a minimum of five years, or the principals/owners must have had ownership/executive management experience in a previous company that provided similar services for a minimum of five years.

The bid notice states Contractor may be liable to the GLO for liquidated damages if contractor fails to meet any milestone.

The bid notice states Contractor shall be responsible for coordinating with the GLO Region 3 representative for prebid site visits and access.

The bid notice states Any respondent unsuccessful or aggrieved in connection with this solicitation may file a protest in accordance with Title 31, Section 3. 50 of the Texas Administrative Code.

The estimated cost to reverse engineer the bilge pump is $2. 63 million, as stated in the notice.

The contractor work completion date is 8 February 2027. Contractor work completion date: 8 february 2027

The contractor shall extend to the government the full coverage of any standard commercial warranty normally offered in a similar commercial sale. he contractor shall extend to the government the full coverage of any standard commercial warranty normally offered in a similar commercial sale

The government will evaluate offers on a LPTA basis. The government will evaluate offers on a lpta basis in accordance with far ****.

Offerors must possess a current and active U. S. Navy MSRA or ABR issued by the U. S. Navy or NAVSUP FLCL. his solicitation has a qualification requirement for offerors to possess a current and active usn msra or abr issued by the u. s. navy or navsup flcy.

To schedule a ship check, offerors shall email a request for a ship check to the POC listed above. o schedule a ship check, offerors shall email a request for a ship check to the poc listed above.

Offerors may submit questions in writing via email to the following points of contact listed above. All questions shall be submitted using attachment III request for information RFI provided with this solicitation. Questions shall be submitted no later than 1 april 2026 12:00 pm Japan Standard Time JST. questions shall be submitted no later than 1 april 2026 12:00 pm japan standard time jst, to ensure the government is able to adequately address and respond to questions submitted.

The contractor work completion date is 8 February 2027. Contractor work completion date: 8 february 2027

The contractor shall extend to the government the full coverage of any standard commercial warranty normally offered in a similar commercial sale. he contractor shall extend to the government the full coverage of any standard commercial warranty normally offered in a similar commercial sale

The government will evaluate offers on a LPTA basis. The government will evaluate offers on a lpta basis in accordance with far ****.

Offerors must possess a current and active U. S. Navy MSRA or ABR issued by the U. S. Navy or NAVSUP FLCL. his solicitation has a qualification requirement for offerors to possess a current and active usn msra or abr issued by the u. s. navy or navsup flcy.

To schedule a ship check, offerors shall email a request for a ship check to the POC listed above. o schedule a ship check, offerors shall email a request for a ship check to the poc listed above.

Offerors may submit questions in writing via email to the following points of contact listed above. All questions shall be submitted using attachment III request for information RFI provided with this solicitation. Questions shall be submitted no later than 1 april 2026 12:00 pm Japan Standard Time JST. questions shall be submitted no later than 1 april 2026 12:00 pm japan standard time jst, to ensure the government is able to adequately address and respond to questions submitted.