Boat Ramp Government Bids & RFPs

The period of performance for this contract is 85 calendar days from the notice to proceed.

Payments will be made monthly, based on an agreed-upon schedule of values.

The contractor must designate a project superintendent and provide satisfactory evidence of liability insurance coverage and workmen's compensation for the contractor and all subcontractors. For concrete work, an installer qualified as an ACI-certified flatwork technician and finisher is required. For quality control, a Waste Management Coordinator with LEED accreditation is required.

The contractor shall field verify all existing conditions affecting the work in this contract before providing pricing or ordering materials. The scheduling of field verification site visits shall be coordinated with the Contracting Officers Representative (COR).

Failure to submit all required documents one week prior to the pre-construction conference may result in the cancellation of the conference, no notice to proceed being issued, and consideration of other contractual remedies. Failure to comply with safety requirements may result in suspension of work. Failure to maintain silt fences and storm drain protection may be cause for an immediate stop-work order.

The bid notice states that all work must be completed on or before October 30, 2026, with the exception of seeding, to be completed by November 13, 2026, and turf establishment which shall be completed by May 1, 2027. all work must be completed on or before october 30, 2026 as shown on the notice to proceed, with the exception of seeding, to be completed by november 13, 2026 and turf establishment which shall be completed by may 1, 2027.

The bid notice indicates that the City agrees to pay ninety percent (90%) of estimates made by the Department of Public Services Engineering semimonthly as the work progresses, with the remaining amount payable upon final acceptance and approval of the work by the City Engineer. paying ninety percent 90 thereof on the basis of estimates made by the department of public services engineering semimonthly as the work progresses, and approved by the city engineer.

The bid notice states that the contractor shall be responsible for and must make good any defects arising or discovered in the work or material required within one (1) year from the completion and final acceptance of such work and material, except for concrete sidewalks, new or repaired, and paving between the curb and sidewalk driveway approaches, which shall be guaranteed for a period of five (5) years. he contractor shall be responsible for and must make good any defects arising or discovered in the work or material required hereunder within one 1 year from the completion and final acceptance of such work and material, except for concrete sidewalks, new or repaired, and paving between the curb and sidewalk driveway approaches, which shall be guaranteed for a period of five 5 years from the completion and final acceptance of such work and material.

The bid notice states that the contract will be awarded to the lowest responsible bidder complying with the conditions of the sealed bid information, provided such bid is reasonable and it is to the interest of the City of Saginaw to accept it. he contract will be awarded to the lowest responsible bidder complying with the conditions of the sealed bid information, provided such bid is reasonable and it is to the interest of the city of saginaw to accept it.

The bid notice requires that all bidders must be Michigan Department of Transportation (MDOT) prequalified in one of the listed work classifications below to bid on this project. all bidders must be michigan department of transportation mdot prequalified in one of the listed work classifications below to bid on this project.

The bid notice mentions that failure by the contractor to meet interim, final, and/or any stage completion dates will result in the assessment of liquidated damages in accordance with subsection **** of the standard specifications for construction, and the special provisions included in the proposal. failure by the contractor to meet interim, final, andor any stage completion dates will result in the assessment of liquidated damages in accordance with subsection **** of the standardspecifications for construction, and the special provisions included in the proposal.

The bid notice states that all disputes arising under this contract or its interpretation shall be presented by the contractor to the city engineer for decision within ten (10) days of commencement of the dispute. all disputes arising under this contract or its interpretation, whether involving law or fact or both, or extra work, and all claims for alleged breach of contract shall within ten 10 days of commencement of the dispute, be presented by the contractor to the city engineer for decision.

The bid notice warns that bids must be submitted on printed forms furnished by the City Purchasing Office, in ink or typewritten, signed, dated, and include delivery or completion time. Failure to submit a bid bond when required, or submitting facsimiles or copies of a bid bond, will result in disqualification. Also, bids must be in the City Purchasing Office by the specified date and time, and unmarked bids will be disqualified. bids must be submitted on printed forms furnished by the city purchasing office. . . . bids must contain bidders complete name, address, and telephone number. . . . bids must be signed in ink and dated. . . . bids must include delivery or completion time. . . . an original bid bond, bank money order, certified check, or cashiers check in the amount of five percent 5 of the total amount bid must be submitted with any bid in excess of 100, 000. the aia document a310 **** bid bond is the preferred format. if the agreement is for multiple years, each year should be combined to get your total cost. facsimiles or copies of bid bond will not be accepted, and bid will be disqualified if submitted. . . . all bids must be in the city purchasing office, **** s. washington ave. saginaw, mi **** by the date and time specified on bid forms. . . . unmarked bids will be disqualified.

The bid notice states that sealed bids will be received until 2:00 PM, June 23, 2026. sealed bids will be received until 2: 00 pm, june 23, 2026

An optional prebid conference will be held May 28, 2026, at 2:00 PM, at the City of League City, Civic Center, 400 W. Walker St. , League City, Texas **** optional prebid conference will be held may 28, 2026, 2026, at 2: 00 pm, at the city of league city, civic center, 400 w. walker st. , league city, texas ****.

The bid notice does not mention the submission of samples. FALSE

The bid notice states that bids received after the specified time will not be accepted. bids received after that time will not be accepted.