Sql Government Bids & RFPs

Offers must be submitted no later than June 26, 2026, 2:00 p. m. CT. Late offers will not be considered.

Payment shall be made in accordance with the Texas Prompt Payment Act, generally no later than 30 days after the later of the date goods are received, services are completed, or an undisputed invoice is received.

Successful respondent represents and warrants that its performance under the contract shall be conducted conscientiously in a professional and workmanlike manner to the full extent of successful respondents talents and capabilities with due diligence and in full compliance with the highest professional standards of practice in the industry applicable to the services.

Offers will be evaluated under the best value standard, with criteria including respondents past performance, qualifications, experience (20%), compliance with CPA specifications (50%), and cost (30%).

Vendors must be qualified and respondents must provide a profile describing the size and scope of operations, general nature of previous similar work, prior contracting experience with CPA and other public sector entities, and financial stability.

In the event of a default or breach of contract, CPA may require the successful respondent to pay, as liquidated damages and not as a penalty, an amount equivalent to two percent of the total cost for services or obligations not completed as required by the contract per calendar day of delay.

Failure of a respondent or any of its representatives to observe the restriction on contacting CPA staff (other than the designated contact person) may result in disqualification of any related offer.

Responses are due June 26, 2026, at 12:00 PM ET. all interested contractors should submit their rfi responses no later than june26, 2026 at 12: 00 pm et.

The completion target for the VMware servers and application server is within 30 days after the award of the contract.

Payment shall be made upon full completion of all VMware servers and application server installations, training, deployment, and acceptance of the project by IHS Shiprock Service Unit COR.

Successful proposals shall include full warranty and service support for 5 years, as well as all hardware updates.

The award will be based on Technical aspects and preferences and Past performance.

Vendors shall supply 3 past performances of contracts supplying the Federal Government with VMware servers and supporting documents of past performance of Powerscribe One installation.

If it is determined by the government that EIT supplies and services provided by the contractor do not conform to the described accessibility standards in the contract, remediation will be the responsibility of the contractor at its own expense.