This is a combined synopsis/solicitation for radiopharmaceuticals for VA Phoenix and Tucson Healthcare Systems. The government intends to award a firm-fixed-price, single-award, IDIQ contract for a base period plus four option years. Quotes are requested, and a written solicitation will not be issued. Shipping is FOB destination and must be included in the unit cost. The NAICS code is **** must be submitted via email by February 6, 2026, at 10:00 AM Pacific Time. Responses are due February 13, 2026, at 10:00 AM Pacific Time. Offerors must be registered in SAM. gov. Pricing must be provided using the attached spreadsheet. The contract begins on the date of award. The contractor must be licensed by the nuclear regulatory commission and be regularly established in the business of providing radiopharmaceuticals. The contractor shall adhere to all federal and state laws and regulations in effect during the term of this contract. The government may terminate this contract as a whole or in part if the contractor fails to meet the required delivery schedule. The contractor shall be liable for a fixed, occurring amount until the government may reasonably obtain delivery of similar supplies. The contractor shall not be charged with damages when the delay in delivery arises beyond control and without the fault or negligence of the contractor. Delivery date and time specified may be adjusted by the contracting officer. The contractor will be notified of this change at least seven 7 days prior to the original or adjusted delivery date. All delivery-related charges, including fuel surcharges, must be incorporated into radiopharmaceutical unit costs. The contractor shall provide miscellaneous supplies and/or services including but not limited to the following upon the governments request: osha compliant monitoring devices. dose calibrator calibration. The solicitation will be in accordance with FAR part 12, 13, and subpart 16. 5, acquisition of commercial items, simplified acquisition procedures, indefinite delivery, and veteran affairs acquisition regulations as supplemented with additional information in this notice.
The bid notice states Orders shall be placed each day monday through friday by 4:30pm for delivery the next business day monday through friday by 06:30 am.
The bid notice states All payments by the government to the contractor will be made in accordance with: ****, payment by electronic funds transfersystem for award management, ****, payment by third party.
The bid notice states The contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.
The bid notice states he government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the government, price is the sole evaluation factor.
The bid notice states The contractor must be regularly established in the business that is called for, and who in the judgment of the contracting officer are financially responsible and able to show evidence of the reliability, ability, experience, equipment, facilities and personnel directly employed or supervised by them to render prompt and satisfactory service.
The bid notice states The government may terminate this contract as a whole or in part if the contractor fails to meet the required delivery schedule. The contractor shall be liable for a fixed, occurring amount until the government may reasonably obtain delivery of similar supplies.
The bid notice states submit any questions regarding this procurement via email to ***@***. *. * no later than 10am pacific local time friday, february 6, 2026.