Warrant Survey Government Bids & RFPs

The bid notice states The purchase shall include manufacturer s warranty for the life of the equipment that begins on the date of installation.

Interested companies shall provide company name and address, point of contact name, email address, phone number, and SAM. gov UEI.

The contractor shall begin performance within 10 calendar days and complete it within **** calendar days after receiving award, notice to proceed. The contractor shall begin performance within 10 calendar days and complete it within **** calendar days after receiving award, notice to proceed.

The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer. The government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the contracting officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the contracting officer.

The award will be made with reasonable promptness to the responsible bidder submitting the lowest responsive bid in accordance with requirements and provisions herein. The award will be made with reasonable promptness to the responsible bidder submitting the lowest responsive bid in accordance with requirements and provisions herein.

All eligible contractors that are capable of successfully completing the work identified in the requirement can submit a bid. All eligible contractors that are capable of successfully completing the work identified in the requirement can submit a bid.

If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of contracting officer insert amount for each calendar day of delay until the work is completed or accepted. If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay liquidated damages to the government in the amount of contracting officer insert amount for each calendar day of delay until the work is completed or accepted.

No site visit will be coordinated for this requirement. o site visit will be coordinated for this requirement

All questions shall be in writing and submitted no later than 15 december 2025 10: 00 am. all questions shall be in writing and submitted no later than 15 december 2025 10: 00 am.

The magnitude of the requirement is between 5, 000, **** and 10, 000, ****. he magnitude of the requirement is between 5, 000, **** and 10, 000, ****.

The bid notice states, must include a minimum 12 month warranty on all parts.

The bid notice states, if applicable this will be awarded to the lowest, responsible and responsive bidder.

The bid notice states, only those bidders/suppliers with an active mbe certification at the time the solicitation closes can submit a response.

The bid notice states deliverable deliverable description format requirements due date warranty coverage and support warranties on trimble equipment currently in service at 12 31 of the contract year software and firmware updates timely updates and upgrades to minimize downtime of equipment. as required during the contract year

The bid notice states he government will pay the contractor a fixed price in arrears, which will constitute full compensation for all contractor professional and incidental services, travel expenses, and materials necessary to complete the requirements as specified in the sow.

The bid notice states warranty coverage and support warranties on trimble equipment currently in service at 12 31 of the contract year

The bid notice states in accordance with 25 u. s. c. 47 the buy indian act, the signature below constitutes selfcertification that the offerormeets the definition of an indian firm hhsar **** with indian ownership hhsar ****, in responseto this solicitation and resultant contract.

The bid notice states any false or misleading information submitted by an enterprise when submitting an offer in consideration of an awardsetaside under the authority of the buy indian act is a violation of the law and punishable under 18 **** claims submitted as part of contract performance are subject to the penalties enumerated in 31 **** **** and 18 u. s. c. 287.