The Texas State University System is seeking statements of qualifications for IDIQ geotechnical, construction material testing, and environmental assessment services. The contract will have a 3-year initial term with two 1-year extension options, with a total value not exceeding $500,000. Submissions are due July 21, 2026. The selection process involves evaluating qualifications, potentially followed by interviews. No pre-submittal conference will be held. Respondents must submit a Vethub Subcontracting Plan. All submitted information is subject to public disclosure.
The deadline for the submittal of qualifications and HSP is July 21, 2026, at 2:00 p. m. C. D. T.
The evaluation of qualifications will be based on specific criteria outlined in the RFQ, including respondents' statement of qualifications and availability, ability to provide services, qualifications of assigned personnel, performance on past engagements, and knowledge of best practices. The owner may select respondents for interviews to further clarify qualifications.
Respondents must submit a complete statement of qualifications addressing specific criteria, including a history of the firm, details of personnel, past project experience, and knowledge of best practices. Incomplete qualifications may be considered nonresponsive.
There will be no pre-submittal conference conducted for this selection process.
Failure to submit specific plans and representations regarding Vethub utilization, or failure to address the subject at all, will be interpreted as an intention not to support the program and will disqualify the respondent. Failure to complete, sign, and return the execution of offer form may also result in disqualification.
The total value of the agreement will not exceed five hundred thousand dollars ($500,000) for the total term of the agreement, including all extensions.