Verdantas - City Of Fort Wright - Ky - Agency Bids & RFPs

The contractor warrants that materials and equipment furnished under the contract will be of good quality and new unless the contract documents require or permit otherwise. the contractor warrants to the owner that materials and equipment furnished under the contract will be of good quality and new unless the contract documents require or permit otherwise.

The city council shall authorize acceptance of the bid made by the responsible bidder who, in council's judgment, offers the best and most responsive proposal to the city, considering quality, service, performance record, and price. the city council of the city of fort wright shall authorize acceptance of the bid made by theresponsible bidder who, in councils judgment, offers the best and most responsive proposal to the city, considering quality, service, performance record, and price

Each bidder must furnish satisfactory evidence that it is operating a business of a type that can meet the specifications for the work and that it has operated such business for at least the last two 2 years. each bidder must furnish satisfactory evidence that it is operating a business of a type that can meet the specifications for the work and that it has operated such business for at least the last two 2 years.

If the contractor neglects, fails, or refuses to complete the work within the allotted time, the contractor does hereby agree to pay to the owner, as liquidated damages and not as a penalty, the amount as stated in the contract for each calendar day beyond the completion date stated in the notice to proce. if the contractor neglects, fails, or refuses to complete the work within the allotted time, or fails to secure an extension of time for delays, the contractor does hereby agree to pay to the owner, as liquidated damages and not as a penalty, theamount as stated in the contract for each calendar day beyond the completion date stated in the notice to proce

Prospective bidders will be permitted to explore the site of the work by boring or test pits, permits for which will be issued by the engineer. subject to public safety and convenience, prospective bidders will be permitted to explore the site of the work by boring or test pits, permits for which will be issued by the engineer.

Before the contract is awarded, the bidder may be required to furnish a complete statement of the origin, composition and manufacturer of any or all materials to be used in the construction of the work together with samples. before the contract is awarded, the bidder may be required to furnish a complete statement of the origin, composition and manufacturer of any or all materials to be used in the construction of the work together with samples,

Any bid submitted unsealed or unsigned, or any bid deemed unresponsive will be disqualified and returned to the bidder. any bid submitted unsealed or unsigned, or any bid deemed unresponsive will be disqualified andreturned to the bidder.

The project is required to be completed no later than July 31, 2026.

The contractor warrants that materials and equipment furnished will be of good quality and new, and the work will conform to contract documents and be free from defects, excluding remedy for damage or defect caused by abuse, alterations, improper maintenance, operation, or normal wear and tear.

The City Council shall authorize acceptance of the bid made by the responsible bidder who, in council's judgment, offers the best and most responsive proposal to the City, considering quality, service, performance record, and price.

Bidders must furnish satisfactory evidence that they have the necessary resources, have operated a business of the type that can meet specifications for at least two years, have sufficient experience, ample equipment and personnel, adequate financial resources, a satisfactory record of integrity and performance, and are otherwise qualified and eligible.

If the contractor fails to execute the contract within the required time, the contractor's bid guaranty may be forfeited to the owner as liquidated damages. Failure to maintain roadway or structure may result in the engineer maintaining the project and deducting the cost from monies due to the contractor.

The bidder is expected to examine the site of the proposed work. Prospective bidders will be permitted to explore the site by boring or test pits, with permits issued by the engineer. Explorations are at the sole risk and expense of the bidder.

Before the contract is awarded, the bidder may be required to furnish a complete statement of the origin, composition, and manufacturer of any or all materials to be used, together with samples, which may be subjected to tests.

Bids may be disqualified if submitted unsealed or unsigned, deemed unresponsive, or submitted without a bid guaranty or an invalid guaranty. Bids may be considered nonresponsive if on a form other than that furnished by the owner, altered, or if there are unauthorized additions, conditional or alternate bids, conditions, or irregularities.