City Of Concord - Nc - Agency Bids & RFPs

The bid notice states that services will be performed in a variety of locations including facility buildings, multi family units, and singlefamily homes.

The bid notice states that contractor warrants that any service provided to the city as a result of this rfp complies with all specifications and other terms and conditions herein set forth, and further warrants and guarantees that said services will be performed in accordance with the defined standard of performance and other terms and conditions as herein specified, in addition to any and all other remedies provided by law, or specified herein, and all remedies will be considered cumulative, and not exclusive.

The bid notice states that a contract shall be awarded in accordance with the terms and conditions of this rfp to one, or a pool of respondents whose proposals are most advantageous to the city of concord considering price, technical and other factors as specified in this rfp.

The bid notice states that his request for proposal is for qualified companies who specialize in lawn care and landscaping by providing equipment, labor and materials necessary to provide services.

The bid notice states that any questions or requests for further information must be submitted in writing no later than 4: 00p. m. , on february 27, 2026 to the housing director noted above by email atcarrm@concordnc. gov.

The completion date of this contract is the date 90 days from the commence date.

Payment will be made under as applicable: the quantities of sidewalk, measured as provided above, will be paid for at the quoted unit price of per cubic yard for installation of concrete sidewalk.

At the end of the observation period and upon notification of approval by the director or the directors representative of such, a one 1 year warranty period shall begin.

The award of the contract, if it is to be awarded, will be made to the lowest responsible quoter.

The contractor shall be responsible for displaying project permits as directed by said permits.

The city and contractor agree that as liquidated damages for delay but not as a penalty the contractor shall pay the city **** for each calendar day that expires after the contract specified time until the remaining outstanding work punchlist is performed by the contractor and until such time as punchlist completion and readiness for final payment is made.

Any claims for additional compensation shall be submitted in writing to the director with detailed justification within thirty 30 days after receipt of the final invoice payment.

The bid notice states services will be performed in a variety of locations including multifamily and single family homes.

The contractor warrants that any service provided to the city as a result of this rfp complies with all specifications and other terms and conditions herein set forth, and further warrants and guarantees that said services will be performed in accordance with the defined standard of performance and other terms and conditions as herein specified, in addition to any and all other remedies provided by law, or specified herein, and all remedies will be considered cumulative, and not exclusive.

A contract shall be awarded in accordance with the terms and conditions of this rfp to one, or a pool of respondents whose proposals are most advantageous to the city of concord considering price, technical and other factors as specified in this rfp.

The city of concord housing department is requesting proposals for interior cleaning services within newly vacant units as identified in the attached scope of services.

Questions or requests for further information must be submitted in writing no later than 4:00 p. m. , on february 9, 2026 to the housing director noted above by email at carrm@concordnc. gov.