The solicitation is for ship repair services for the USS HIGGINS DDG 76 CMAV. The award is restricted to firms with a current master shiprepair agreement (MSRA) or boat repair (ABR) agreement. Offers must be submitted by February 11, 2026, at 12:00 PM local time. All questions must be submitted no later than 05 February 2026, 1500hrs Singapore time.
The delivery schedule is from 28 Feb 2026 to 19 Mar 2026. overall contract delivery periodcontractordestination line item delivery schedule quantity address and poc period of performance 1 job from **** 28 feb 2026 to 19 mar 2026
The contractor shall apply a permanent warranty notification stamping or marking on each warranted deliverable end item and its container. he contractor shall apply a permanent warranty notification stamping or marking on each warranted deliverable end item and its container.
Award will be made to the responsible offeror whose proposal offers the lowest evaluated price and for which nonprice factor technical is rated as acceptable. award will be made to the responsible offeror whose proposal offers the lowest evaluated priceand for which nonprice factor technical is rated as acceptable
Award of a job order resulting from this solicitation is restricted to firms, which possess a current master shiprepair agreement (MSRA) agreement of boat repair (ABR) and is restricted to firms which have a current updated registration in system for awards management. award of a job order resulting from this solicitation is restricted to firms, which possess a current master shiprepair agreementmsra agreement of boat repair abr and is restricted to firms which have a current updated registrationin system for awardsmanagement.
If the contractor fails to deliver the supplies or perform the services within the time specified in this contract, the contractor shall, in place of actual damages, pay to the government liquidated damages of 42,**** per calendar day of delay. if the contractor fails to deliver the supplies or perform the services within the time specified in this contract, the contractor shall, in place ofactual damages, pay to the government liquidated damages of 42, **** per calendar day of delay contracting officer insert amount.
All questions with regards to this solicitation are to be submitted no later than 05 February 2026, 1500hrs Singapore time. all questions with regards to this solicitation are to be submitted no later than 05 february 2026, 1500hrs singapore time utilizingattachment j4 in section j.