Warranty Government Bids & RFPs

The bid notice states unless otherwise specified all materials, supplies or equipment quoted herein must be delivered within thirty 30 days from date of notification of award or by exception noted on bid sheet.

The bid notice states payment terms are net 30 unless otherwise specified.

The bid notice states statement of warranty required.

The bid notice states he following criteria are used in determining low responsible bidder: a the ability, capacity and skill of bidder to perform required service. b whether bidder can perform service promptly or within specified time. c the character, integrity, reputation, judgment, experience and efficiency of bidder. d the performance of previous contracts. e the suitability of equipment or material for city use. f the ability of bidder to provide future maintenance and parts service.

The bid notice states all bidders must be recognized and authorized dealers in the materials or equipment specified and be qualified to instruct in their application or use.

The bid notice states sample required with bid.

The bid notice states questions deadline: 2: 30pm on ****.

The project must be substantially completed within sixtythree 63 consecutive calendar days after written notice to proceed. Construction time: sixtythree 63 consecutive calendar days after written notice to proceed.

The owner shall make progress payments on account of the contract sum to the contractor as provided below and elsewhere in the contract document. Based upon applications for payment submitted to the architect by the contractor and certificates for payment issued by the architect, the owner shall make progress payments on account of the contract sum to the contractor as provided below and elsewhere in the contract document.

The manufacturer shall warrant all work performed under these specifications to be free of defects for a period of one year. he manufacturer shall warrant all work performed under these specifications to be free of defects for a period of one year.

Award of the contract will be made to the lowest responsible bidder for the actual amount bid. Award of the contract will be made to the lowest responsible bidder for the actual amount bid

Bidders for this project are required to hold a current certificate of prequalification issued by the school board of volusia county florida at the time of bid opening. bidders for this project are required to hold a current certificate of prequalification issued by the school board of volusia county florida at the time of bid opening.

The contractor and the contractors surety shall be liable for and shall pay, as liquidated damages, the sum of one hundred fifty dollars and no cents **** per calendar day for each calendar day or part thereof, the delay in the project continues beyond the deadline set by the terms of the contract for substantial completion of the work. he contractor and the contractors surety shall be liable for and shall pay, as liquidated damages, the sum of one hundred fifty dollars and no cents **** per calendar day for each calendar day or part thereof, the delay in the project continues beyond the deadline set by the terms of the contract for substantial completion of the work.

A mandatory prebid conference is scheduled for March 12, 2026, at 11:00 am at location southwestern middle school, 605 w. new hampshire avenue, deland, florida **** bidders must attend. a mandatory prebid conference is scheduled for date ****, time 11: 00 am at locationsouthwestern middle school, 605 w. new hampshire avenue, deland, florida **** bidders mustattend.